SECTION A NOTICE INVITING BIDS CITY OF ENCINITAS Paul Ecke Central Improvements, A CDBG Project CS16D Sealed bids will be received at the office of the City Clerk, City Hall, City of Encinitas, 505 S. Vulcan Avenue, Encinitas, CA 92024, until 3:00 p.m., June 28, 2016. Envelopes should state “Sealed bid of Project CS16D. Do not open until 3:00 p.m. on June 28, 2016.” Bids should be addressed to: Kathy Hollywood City Clerk 505 S. Vulcan Avenue Encinitas, California 92024 At 3:00 p.m., the bids will be publicly opened by the City Clerk and read aloud, for performing the work as follows: Paul Ecke Central Inprovements CS16D WORK TO BE DONE: The work to be done generally includes: The work consists of clearing and grubbing including removal of vegetation, grading, installation of masonry block wall, concrete curb ramp, concrete sidewalk, concrete curb, concrete median, unit pavers, landscaping, fence, DG path, and related appurtenant work not mentioned above but required in accordance with Contract Documents to install sidewalk and retaining walls along Paul Ecke Elementary School. The Contractor shall complete the proposed work in its entirety. Should any detail or details be omitted from the Contract Documents which are essential to its functional completeness, then it shall be the responsibility of the Contractor to furnish and install such detail or request such details from the City Engineer so that upon completion of the proposed work, the work will be acceptable and ready for use. Engineer’s Estimate – $340,000 COMPLETION OF WORK: The Contractor shall diligently prosecute the work to completion within twenty five (25) working days from the commencement date contained in the Notice to Proceed. LOWEST RESPONSIVE AND RESPONSIBLE BIDDER: All bids are to be compared on the basis of the City Engineer’s estimate of the quantities of work to be done and the unit prices bid by the bidder. The award of the contract, if it is awarded, will be to the lowest responsive and responsible bidder. Pursuant to Public Contract Code Section 1103, a “Responsible Bidder”, means a bidder who has demonstrated the attributes of trustworthiness, as well as quality, fitness, capacity, and experience to satisfactorily perform this public works contract. FIFTY PERCENT “OWN FORCES” REQUIREMENT: Any bid that proposes performance of more than 50 percent of the work by subcontractors or owner operator/lessors or otherwise to be performed by forces other than the Bidder’s own organization will be rejected as non-responsive. OBTAINING CONTRACT DOCUMENTS: Contract documents may be obtained after Monday, June 20 at the Engineering counter in City Hall located at 505 S. Vulcan Ave., Encinitas, CA 92024, at a non-refundable cost of $50.00 per set. In compliance with California Contract Code, Section 20103.7 electronic copies will be made available to contractor plan series bid boards and contractors upon their request. The project plans and specifications can be electronically downloaded on the City’s ftp site. Please contact Matt Widelski at (760) 633-2862 or [email protected] to get instructions on how to access the City’s ftp site and to download the project plans and specifications electronically. The City makes no representation regarding the accuracy of Contract Documents received from third party plan rooms and Contractor accepts bid documents from third parties at its own risk. It is highly recommended that contractors interested in the project either pick up project plans and specifications directly from the Encinitas Engineering Counter at City Hall or to download them electronically from the City’s ftp site. Should contractors choose to pick up project plans and specifications at Plan Rooms, the contractors shall still be responsible for obtaining all addenda for the project and signing and submitting all addendums with their bid. Any contractor that does not acknowledge receipt of all addendums by signing and submitting all addendums with their bid shall be deemed a non-responsive bidder and their bid will be rejected. BID INFORMATION: Bids will be submitted in sealed envelopes upon the blank forms furnished by the City. No bid will be considered unless it is made on a proposal form furnished by the City. The work shall be in strict conformity with the Contract documents. In order to bid this project, the Contractor must have at the time of bid award a valid Class A State of California Contractor’s License in good standing and must maintain said license in good standing throughout the course of the project. Certain specialty licenses may be required of certain work as set forth in the plans and specifications. The Contractor is responsible to insure that all proper licenses are maintained. No bid will be awarded to a Contractor who is not licensed in accordance with the provisions of chapter 9, Division 3 of the Business and Professions Code. Withdrawal of bids by Contractor shall not be permitted for a period of ninety (90) days after the date set for the opening thereof. BID SECURITY: Each bid must be accompanied by cash, certified or cashier’s check, or bidder’s bond made payable to the City of Encinitas for an amount equal to at least ten percent (10%) of the amount bid, such guarantee to be forfeited should the bidder to whom the contract is awarded fail to enter into the contract. PRE-BID QUESTIONS: The City will answer information requests on this project up to Noon on Thursday, June 23, 2016. After Noon on Thursday, June 23, 2016 no more questions or information requests will be answered and only plan holders list will be either e-mailed or faxed to interested parties during that time. All questions regarding the Contract Documents shall be submitted by e-mail only and must be directed to Matt Widelski [email protected]. All City substantive responses will be provided to all properly registered plan holders by addenda or other written means of communication. LIQUIDATED DAMAGES: The Contractor shall pay to the City of Encinitas the sum of Two-Thousand Dollars ($2,000.00) per day for each and every calendar day of unexcused total project delay in completing the work in excess of the number of working days prescribed above. EQUALS: Notwithstanding if the project plans or specifications designate specific brands, materials, items or trade names, the Bidder may submit proposed equals to the Contract, pursuant to Public Contract Code Section 3400. Any contractor seeking a request for a substitution of “an equal” item shall submit all necessary data substantiating a request at least five business days prior to the bid opening date. RIGHT TO REJECT ALL BIDS: The City reserves the right to reject all bids at its sole discretion and to waive any immaterial irregularities or informalities in the bids received. PREVAILING WAGE: This is a prevailing wage project and prevailing wage rates for this locality and project as determined by the director of industrial relations apply, pursuant to labor code section 1770, et. Seq. A copy of the prevailing wage rates shall be posted on the job site by the contractor. A schedule of prevailing wage rates is available for review at the City’s offices or may be found on the internet at http://www.dir.ca.gov/Public-Works/Prevailing-Wage.html. The successful bidder shall be required to pay at least the wage rates set forth in that schedule. Wage rates shall conform to the Davis-Bacon Act. Contractors shall pay the higher of either the minimum federal wage rates or State prevailing wage rates. Federal minimum wage rates applicable to this project have been determined by the Secretary of Labor and are set forth in the Reference Documents as a General Wage Decision. In accordance with the provisions of the Davis-Bacon Act (40 U.S.C. 276 to a-7) as amended (29 CFR, Part 5), the Contractor shall be required to pay wages to laborers and mechanics at a rate not less than the wage rate determinations of the Secretary of Labor. Federal prevailing wage rates for various labor classifications have been included in the project specifications. A copy of the prevailing wage rates shall be posted on the job site by the Contractor. A schedule of prevailing wage rates is available for review at the City’s offices. Questions pertaining to State predetermined wage rates should be directed to the State department of Industrial Relations website at www.dir.gov . The successful bidder shall be required to pay at least the wage rates set forth in that schedule. The prime contractor shall be responsible for ensuring compliance with all applicable provisions of the Labor Code including, but not limited to, Section 1777.5. Certified Payroll records shall be maintained by the contractor and copies of the certified payroll shall be electronically sent to the Department of Industrial Relations and be delivered to the City at the end of each month during the entire duration of the project. Notice: Subject to exceptions as set forth in Labor Code section 1771.1, contractor or subcontractor shall not be qualified to bid on, be listed in a bid proposal, subject to the requirements of Section 4104 of the Public Contract Code, or engage in the performance of any contract for public work, as defined by statute, unless it is currently registered and qualified to perform public work pursuant to Labor Code Section 1725.5. The City may not accept a bid nor any contract or subcontract entered into without proof of the contractor or subcontractor’s current registration to perform public work pursuant to Section 1725.5. For more information, go to http://www.dir.ca.gov/Public-Works/Certified-Payroll-Reporting.html COMPLIANCE WITH LABOR LAWS: The prime contractor shall be responsible for insuring compliance with all applicable provisions of the Labor Code, including, but not limited to, section 1777.5.
SUBLETTING AND SUBCONTRACTING FAIR PRACTICES ACT: Contractor shall comply with sections 4100 et. seq. of the Public Contracts Code (“Subletting and Subcontracting Fair Practices Act) in all respects. The City is the “duly authorized officer” for the purposes of sections 4107 and 4107.5. PERFORMANCE AND PAYMENT BONDS: Each bid shall be accompanied by security in a form and amount as required by law. The successful bidder will be required to furnish a Payment Bond for one hundred percent (100%), and a Performance Bond for one hundred percent (100%) of the contract amount prior to execution of the contract. The City requires the awarded contractor obtain Payment and Performance bonds, issued by an admitted carrier, qualified to do business in California, as required by Code of Civil Procedure Section 995.120. Pursuant to Public Contract Code section 22300, the City permits the substitution of securities for any moneys withheld to ensure performance under the contract, or, alternatively, the contractor may request and the City may make payment of retentions earned directly to the escrow agent at the expense of the Contractor. FEDERAL REQUIREMENTS: The Prime Contractor shall be responsible for ensuring compliance with related Federal regulations and laws, including those specified in the Contract Documents. Disadvantaged Business Enterprises (DBEs), Underutilized Disadvantaged Business Enterprises (UDBEs), and other small businesses are strongly encouraged to participate in the performance of this work. All Bidders shall refer to the project Specifications for important DBE/UDBE requirements for the performance of this work. Federal Section 3 regulations apply to this CDBG project. All Bidders shall refer to the project Specifications for important Section 3 requirements for the performance of this work. NONDISCRIMINATION: During the performance of this contract, the contractor and its subcontractors shall not deny the contract’s benefits to any person on the basis of on race or color; religion; national origin or ancestry, physical disability; mental disability or medical condition; marital status; sex or sexual orientation; age, with respect to persons over the age of 40; and pregnancy, childbirth, or related medical conditions; nor shall they discriminate unlawfully against any employee or applicant for employment because of on race or color; religion; national origin or ancestry, physical disability; mental disability or medical condition; marital status; sex or sexual orientation; age, with respect to persons over the age of 40; and pregnancy, childbirth, or related medical conditions. Contractor shall insure that the evaluation and treatment of employees and applicants for employment are free of such discrimination. PROJECT ADMINISTRATION: All questions relative to this project prior to the opening of bids, including instructions on how to access the City’s ftp site to download the plans and specifications electronically, shall be directed to the City Representative stated below. The bidder shall not rely upon any representations made by City representatives in preparing its bid, but shall rather rely solely upon the written Contract Documents and any contract addenda issued prior to bid opening. City of Encinitas 505 South Vulcan Avenue Encinitas, CA 92024 Telephone: (760) 633-2862 E-mail: [email protected] ttention: Matt Widelski Associate Civil Engineer Please also see INFORMATION AND INSTRUCTIONS FOR BIDDERS in bid documents for additional bid information and requirements. City of Encinitas BY: Glenn Pruim, PE Director of Public Works DATE: June 17, 2017 END OF NOTICE INVITING BIDS 06/17/16, 06/24/16 CN 18798
APN: 223-383-65-00 TS No: CA08002010-14-1 TO No: 6221034 NOTICE OF TRUSTEE’S SALE YOU ARE IN DEFAULT UNDER A DEED OF TRUST DATED November 3, 2004. UNLESS YOU TAKE ACTION TO PROTECT YOUR PROPERTY, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDINGS AGAINST YOU, YOU SHOULD CONTACT A LAWYER. On July 13, 2016 at 10:30 AM, at the entrance to the East County Regional Center by statue, 250 E. Main Street, El Cajon, CA 92020, MTC Financial Inc. dba Trustee Corps, as the duly Appointed Trustee, under and pursuant to the power of sale contained in that certain Deed of Trust recorded on November 16, 2004, as Instrument No. 2004-1085077, of official records in the Office of the Recorder of San Diego County, California, executed by YVETTE COLON, A SINGLE WOMAN, as Trustor(s), in favor of FIRST FRANKLIN FINANCIAL CORPORATION, SUBSIDIARY OF NATIONAL CITY BANK OF INDIANA as Beneficiary, WILL SELL AT PUBLIC AUCTION TO THE HIGHEST BIDDER, in lawful money of the United States, all payable at the time of sale, that certain property situated in said County, California describing the land therein as: AS MORE FULLY DESCRIBED IN SAID DEED OF TRUST The property heretofore described is being sold “as is”. The street address and other common designation, if any, of the real property described above is purported to be: 7756 CORTE PROMENADE, CARLSBAD, CA 92009 The undersigned Trustee disclaims any liability for any incorrectness of the street address and other common designation, if any, shown herein. Said sale will be made without covenant or warranty, express or implied, regarding title, possession, or encumbrances, to pay the remaining principal sum of the Note(s) secured by said Deed of Trust, with interest thereon, as provided in said Note(s), advances if any, under the terms of the Deed of Trust, estimated fees, charges and expenses of the Trustee and of the trusts created by said Deed of Trust. The total amount of the unpaid balance of the obligations secured by the property to be sold and reasonable estimated costs, expenses and advances at the time of the initial publication of this Notice of Trustee’s Sale is estimated to be $717,997.94 (Estimated). However, prepayment premiums, accrued interest and advances will increase this figure prior to sale. Beneficiary’s bid at said sale may include all or part of said amount. In addition to cash, the Trustee will accept a cashier’s check drawn on a state or national bank, a check drawn by a state or federal credit union or a check drawn by a state or federal savings and loan association, savings association or savings bank specified in Section 5102 of the California Financial Code and authorized to do business in California, or other such funds as may be acceptable to the Trustee. In the event tender other than cash is accepted, the Trustee may withhold the issuance of the Trustee’s Deed Upon Sale until funds become available to the payee or endorsee as a matter of right. The property offered for sale excludes all funds held on account by the property receiver, if applicable. If the Trustee is unable to convey title for any reason, the successful bidder’s sole and exclusive remedy shall be the return of monies paid to the Trustee and the successful bidder shall have no further recourse. Notice to Potential Bidders If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a Trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a Trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same Lender may hold more than one mortgage or Deed of Trust on the property. Notice to Property Owner The sale date shown on this Notice of Sale may be postponed one or more times by the Mortgagee, Beneficiary, Trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about Trustee Sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sale date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call In Source Logic at 702-659-7766 for information regarding the Trustee’s Sale or visit the Internet Web site address listed below for information regarding the sale of this property, using the file number assigned to this case, CA08002010-14-1. Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. Date: June 9, 2016 MTC Financial Inc. dba Trustee Corps TS No. CA08002010-14-1 17100 Gillette Ave Irvine, CA 92614 949-252-8300 TDD: 866-660-4288 Miguel Ochoa, Authorized Signatory SALE INFORMATION CAN BE OBTAINED ON LINE AT www.insourcelogic.com FOR AUTOMATED SALES INFORMATION PLEASE CALL: In Source Logic AT 702-659-7766 MTC Financial Inc. dba Trustee Corps MAY BE ACTING AS A DEBT COLLECTOR ATTEMPTING TO COLLECT A DEBT. ANY INFORMATION OBTAINED MAY BE USED FOR THAT PURPOSE. Order no. CA16-002065-1, Pub Dates, 06/17/2016, 06/24/2016, 07/01/2016. CN 18796
T.S. No. 15-36431 APN: 160-621-43-00 NOTICE OF TRUSTEE’S SALE YOU ARE IN DEFAULT UNDER A DEED OF TRUST DATED 5/25/2005. UNLESS YOU TAKE ACTION TO PROTECT YOUR PROPERTY, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDING AGAINST YOU, YOU SHOULD CONTACT A LAWYER. A public auction sale to the highest bidder for cash, cashier’s check drawn on a state or national bank, check drawn by a state or federal credit union, or a check drawn by a state or federal savings and loan association, or savings association, or savings bank specified in Section 5102 of the Financial Code and authorized to do business in this state will be held by the duly appointed trustee as shown below, of all right, title, and interest conveyed to and now held by the trustee in the hereinafter described property under and pursuant to a Deed of Trust described below. The sale will be made, but without covenant or warranty, expressed or implied, regarding title, possession, or encumbrances, to pay the remaining principal sum of the note(s) secured by the Deed of Trust, with interest and late charges thereon, as provided in the note(s), advances, under the terms of the Deed of Trust, interest thereon, fees, charges and expenses of the Trustee for the total amount (at the time of the initial publication of the Notice of Sale) reasonably estimated to be set forth below. The amount may be greater on the day of sale. Trustor: GILBERT M BRIZENO AND MARVYL J BRIZENO HUSBANDAND WIFE AS JOINT TENANTS Duly Appointed Trustee: LAW OFFICES OF LES ZIEVE Deed of Trust recorded 6/1/2005 as Instrument No. 2005-0456345 in book , page of Official Records in the office of the Recorder of San Diego County, California, Date of Sale:7/11/2016 at 10:30 AM Place of Sale: AT THE ENTRANCE TO THE EAST COUNTY REGIONAL CENTER BY STATUE, 250 E. MAIN STREET, EL CAJON, CA 92020 Estimated amount of unpaid balance and other charges: $1,059,723.20 Note: Because the Beneficiary reserves the right to bid less than the total debt owed, it is possible that at the time of the sale the opening bid may be less than the total debt owed. Street Address or other common designation of real property: 485 LEXINGTON CIRCLE OCEANSIDE, CA 92057 Described as follows: As more fully described on said Deed of Trust. A.P.N #.: 160-621-43-00 The undersigned Trustee disclaims any liability for any incorrectness of the street address or other common designation, if any, shown above. If no street address or other common designation is shown, directions to the location of the property may be obtained by sending a written request to the beneficiary within 10 days of the date of first publication of this Notice of Sale. NOTICE TO POTENTIAL BIDDERS: If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same lender may hold more than one mortgage or deed of trust on the property. NOTICE TO PROPERTY OWNER: The sale date shown on this notice of sale may be postponed one or more times by the mortgagee, beneficiary, trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about trustee sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sale date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call (714) 848-9272 or or visit this Internet Web site www.elitepostandpub.com, using the file number assigned to this case 15-36431. Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. Dated: 6/10/2016 Law Offices of Les Zieve, as Trustee 30 Corporate Park, Suite 450 Irvine, CA 92606 For Non-Automated Sale Information, call: (714) 848-7920 For Sale Information: (714) 848-9272 or www.elitepostandpub.com Natalie Franklin, Trustee Sale Officer THIS FIRM IS ATTEMPTING TO COLLECT A DEBT AND ANY INFORMATION WE OBTAINED WILL BE USED FOR THAT PURPOSE. EPP 18232 6/17, 6/24, 7/1/16 CN 18793
NOTICE OF TRUSTEE’S SALE TS No. CA-14-651464-CL Order No.: 782080 NOTE: THERE IS A SUMMARY OF THE INFORMATION IN THIS DOCUMENT ATTACHED TO THE COPY PROVI DED TO THE MORTGAGOR OR TRUSTOR (Pursuant to Cal. Civ. Code 2923.3) YOU ARE IN DEFAULT UNDER A DEED OF TRUST DATED 4/21/2005. UNLESS YOU TAKE ACTION TO PROTECT YOUR PROPERTY, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDING AGAINST YOU, YOU SHOULD CONTACT A LAWYER. A public auction sale to the highest bidder for cash, cashier’s check drawn on a state or national bank, check drawn by state or federal credit union, or a check drawn by a state or federal savings and loan association, or savings association, or savings bank specified in Section 5102 to the Financial C ode and authorized to do business in this state, will be held by duly appointed trustee. The sale will be made, but without covenant or warranty, expressed or implied, regarding title, possession, or encumbrances, to pay the remaining principal sum of the note(s) secured by the Deed of Trust, with interest and late charges thereon, as provided in the note(s), advances, under the terms of the Deed of Trust, interest thereon, fees, charges and expenses of the Trustee for the total amount (at the time of the initial publication of the Notice of Sale) reasonably estimated to be set forth below. The amount may be greater on the day of sale. BENEFICIARY MAY ELECT TO BID LESS THAN THE TOTAL AMOUNT DUE. Trustor (s): THEODORUS BAKKER, A MARRIED MAN AS HIS SOLE AND SEPARATE PROPERTY Recorded: 4/28/2005 as Instrument No. 2005-0357371 and modified as per Modification Agreement recorded 11/7/2005 as Instrument No. 2005-0966420 of Official Records in the office of the Recorder of SAN DIEGO County, California; Date of Sale: 7/26/2016 at 10:00 AM Place of Sale: At the entrance to the East County Regional Center by the statue, 250 E. Main St., El Cajon, CA. Amount of unpaid balance and other charges: $1,063,425.91 The purported property address is: 3198 CAMINO PORTOFINO, FALLBROOK, CA 92028 Assessor’s Parcel No.: 124-041-08-00 NOTICE TO POTENTIAL BIDDERS: If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same lender may hold more than one mortgage or deed of trust on the property. NOTICE TO PROPERTY OWNER: The sale date shown on this notice of sale may be postponed one or more times by the mortgagee, beneficiary, trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about trustee sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sa le date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call 916-939-0772 for information regarding the trustee’s sale or visit this Internet Web site http://www.qualityloan.com , using the file number assigned to this foreclosure by the Trustee: CA-14-651464-CL . Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. The undersigned Trustee disclaims any liability for any incorrectness of the property address or other common designation, if any, shown herein. If no street address or other common designation is shown, directions to the location of the property may be obtained by sending a written request to the beneficiary within 10 days of the date of first publication of this Notice of Sale. If the Trustee is unable to convey title for any reason, the successful bidder’s sole and exclusive remedy shall be the return of monies paid to the Trustee, and the successful bidder shall have no further recourse. If the sale is set aside for any reason, the Purchaser at the sale shall be entitled only to a return of the deposit paid. The Purchaser shall have no further recourse against the Mortgagor, the Mortgagee, or the Mortgagee’s Attorney. If you have previously been discharged through bankruptcy, you may have been released of personal liability for this loan in which case this letter is intended to exercise the note holders right’s against the real property only. As required by law, you are hereby notified that a negative credit report reflecting on your credit record may be submitted to a credit report agency if you fail to fulfill the terms of your credit obligations. QUALITY MAY BE CONSIDERED A DEBT COLLECTOR ATTEMPTING TO COLLECT A DEBT AND ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE . Date: Quality Loan Service Corporation 411 Ivy Street San Diego, CA 92101 619-645-7711 For NON SALE information only Sale Line: 916-939-0772 O r Login to: http://www.qualityloan.com Reinstatement Line: (866) 645-7711 Ext 5318 Quality Loan Service Corp. TS No.: CA-14-651464-CL IDSPub #0109032 6/10/2016 6/17/2016 6/24/2016 CN 18769
T.S. No.: 2014-07890-CA A.P.N.:190-180-12-00 Property Address: 26335 Engelmann Road, Valley Center, CA 92082-7360 NOTICE OF TRUSTEE’S SALE PURSUANT TO CIVIL CODE § 2923.3(a), THE SUMMARY OF INFORMATION REFERRED TO BELOW IS NOT ATTACHED TO THE RECORDED COPY OF THIS DOCUMENT BUT ONLY TO THE COPIES PROVIDED TO THE TRUSTOR. NOTE: THERE IS A SUMMARY OF THE INFORMATION IN THIS DOCUMENT ATTACHED 注：本文件包含一个信息摘要 참고사항: 본 첨부 문서에 정보 요약서가 있습니다 NOTA: SE ADJUNTA UN RESUMEN DE LA INFORMACIÓN DE ESTE DOCUMENTO TALA: MAYROONG BUOD NG IMPORMASYON SA DOKUMENTONG ITO NA NAKALAKIP LƯU Ý: KÈM THEO ĐÂY LÀ BẢN TRÌNH BÀY TÓM LƯỢC VỀ THÔNG TIN TRONG TÀI LIỆU NÀY IMPORTANT NOTICE TO PROPERTY OWNER: YOU ARE IN DEFAULT UNDER A DEED OF TRUST DATED 04/13/2007. UNLESS YOU TAKE ACTION TO PROTECT YOUR PROPERTY, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDING AGAINST YOU, YOU SHOULD CONTACT A LAWYER. Trustor: Adrian Costilla and Irene Costilla, Husband and Wife as Joint Tenants Duly Appointed Trustee: Western Progressive, LLC Recorded 04/24/2007 as Instrument No. 2007-0275536 in book —, page— and of Official Records in the office of the Recorder of San Diego County, California, Date of Sale: 07/12/2016 at 10:30 AM Place of Sale: AT THE ENTRANCE TO THE EAST COUNTY REGIONAL CENTER BY THE STATUE, 250 E. MAIN STREET, EL CAJON, CA 92020 Estimated amount of unpaid balance and other charges: $ 662,213.67 NOTICE OF TRUSTEE’S SALE WILL SELL AT PUBLIC AUCTION TO HIGHEST BIDDER FOR CASH, CASHIER’S CHECK DRAWN ON A STATE OR NATIONAL BANK, A CHECK DRAWN BY A STATE OR FEDERAL CREDIT UNION, OR A CHECK DRAWN BY A STATE OR FEDERAL SAVINGS AND LOAN ASSOCIATION, A SAVINGS ASSOCIATION OR SAVINGS BANK SPECIFIED IN SECTION 5102 OF THE FINANCIAL CODE AND AUTHORIZED TO DO BUSINESS IN THIS STATE: All right, title, and interest conveyed to and now held by the trustee in the hereinafter described property under and pursuant to a Deed of Trust described as: More fully described in said Deed of Trust. Street Address or other common designation of real property: 26335 Engelmann Road, Valley Center, CA 92082-7360 A.P.N.: 190-180-12-00 The undersigned Trustee disclaims any liability for any incorrectness of the street address or other common designation, if any, shown above. The sale will be made, but without covenant or warranty, expressed or implied, regarding title, possession, or encumbrances, to pay the remaining principal sum of the note(s) secured by the Deed of Trust. The total amount of the unpaid balance of the obligation secured by the property to be sold and reasonable estimated costs, expenses and advances at the time of the initial publication of the Notice of Sale is: $ 662,213.67. If the Trustee is unable to convey title for any reason, the successful bidder’s sole and exclusive remedy shall be the return of monies paid to the Trustee, and the successful bidder shall have no further recourse. The beneficiary of the Deed of Trust has executed and delivered to the undersigned a written request to commence foreclosure, and the undersigned caused a Notice of Default and Election to Sell to be recorded in the county where the real property is located. NOTICE TO POTENTIAL BIDDERS: If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same lender may hold more than one mortgage or deed of trust on this property. NOTICE OF TRUSTEE’S SALE Note: Because the Beneficiary reserves the right to bid less than the total debt owed, it is possible that at the time of the sale the opening bid may be less than the total debt NOTICE TO PROPERTY OWNER: The sale date shown on this notice of sale may be postponed one or more times by the mortgagee, beneficiary, trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about trustee sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sale date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call (866)-960-8299 or visit this Internet Web site http://www.altisource.com/MortgageServices/DefaultManagement/TrusteeServices.aspx using the file number assigned to this case 2014-07890-CA. Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. Date: June 1, 2016 Western Progressive, LLC, as Trustee for beneficiary C/o 30 Corporate Park, Suite 450 Irvine, CA 92606 Automated Sale Information Line: (866) 960-8299 http://www.altisource.com/MortgageServices/DefaultManagement/TrusteeServices.aspx For Non-Automated Sale Information, call: (866) 240-3530 Trustee Sale Assistant WESTERN PROGRESSIVE, LLC MAY BE ACTING AS A DEBT COLLECTOR ATTEMPTING TO COLLECT A DEBT. ANY INFORMATION OBTAINED MAY BE USED FOR THAT 06/10/16, 06/17/16, 06/24/16 CN 18768
NOTICE OF TRUSTEE’S SALE TS No. CA-14-630363-CL Order No.: 730-1404443-70 YOU ARE IN DEFAULT UNDER A DEED OF TRUST DATED 12/15/2006. UNLESS YOU TAKE ACTION TO PROTECT YOUR PROPERTY, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDING AGAINST YOU, YOU SHOULD CONTACT A LAWYER. A public auction sale to the highest bidder for cash, cashier’s check drawn on a state or national bank, check drawn by state or federal credit union, or a check drawn by a state or federal savings and loan association, or savings association, or savings bank specified in Section 5102 to the Financial Code and authorized to do business in this state, will be held by duly appointed trustee. The sale will be made, but without covenant or warranty, expressed or implied, regarding title, possession, or encumbrances, to pay the remaining principal sum of the note(s) secured by the Deed of Trust, with interest and late charges thereon, as provided in the note(s), advances, under the terms of the Deed of Trust, interest thereon, fees, charges and expenses of the Trustee for the total amount (at the time of the initial publication of the Notice of Sale) reasonably estimated to be set forth below. The amount may be greater on the day of sale. BENEFICIARY MAY ELECT TO BID LESS THAN THE TOTAL AMOUNT DUE. Trustor(s): Scott Monson, a single man Recorded: 12/20/2006 as Instrument No. 2006-0902254 of Official Records in the office of the Recorder of SAN DIEGO County, California; Date of Sale: 7/1/2016 at 10:30AM Place of Sale: At the front entrance to the building located at 321 N. Nevada Street Oceanside, California 92054 Amount of unpaid balance and other charges: $748,238.50 The purported property address is: 1508 LAUREL ROAD, OCEANSIDE, CA 92054 Assessor’s Parcel No.: 151-260-08-00 NOTICE TO POTENTIAL BIDDERS: If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same lender may hold more than one mortgage or deed of trust on the property. NOTICE TO PROPERTY OWNER: The sale date shown on this notice of sale may be postponed one or more times by the mortgagee, beneficiary, trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about trustee sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sale date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call 888-988-6736 for information regarding the trustee’s sale or visit this Internet Web site http://www.qualityloan.com , using the file number assigned to this foreclosure by the Trustee: CA-14-630363-CL . Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. The undersigned Trustee disclaims any liability for any incorrectness of the property address or other common designation, if any, shown herein. If no street address or other common designation is shown, directions to the location of the property may be obtained by sending a written request to the beneficiary within 10 days of the date of first publication of this Notice of Sale. If the Trustee is unable to convey title for any reason, the successful bidder’s sole and exclusive remedy shall be the return of monies paid to the Trustee, and the successful bidder shall have no further recourse. If the sale is set aside for any reason, the Purchaser at the sale shall be entitled only to a return of the deposit paid. The Purchaser shall have no further recourse against the Mortgagor, the Mortgagee, or the Mortgagee’s Attorney. If you have previously been discharged through bankruptcy, you may have been released of personal liability for this loan in which case this letter is intended to exercise the note holders right’s against the real property only. As required by law, you are hereby notified that a negative credit report reflecting on your credit record may be submitted to a credit report agency if you fail to fulfill the terms of your credit obligations. QUALITY MAY BE CONSIDERED A DEBT COLLECTOR ATTEMPTING TO COLLECT A DEBT AND ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE. Date: Quality Loan Service Corporation 411 Ivy Street San Diego, CA 92101 619-645-7711 For NON SALE information only Sale Line: 888-988-6736 Or Login to: http://www.qualityloan.com Reinstatement Line: (866) 645-7711 Ext 5318 Quality Loan Service Corp. TS No.: CA-14-630363-CL IDSPub #0108952 6/10/2016 6/17/2016 6/24/2016 CN 18767
APN: 257-080-03-01 TS No: CA07000299-16-1 TO No: 160044407-CA-DMI NOTICE OF TRUSTEE’S SALE YOU ARE IN DEFAULT UNDER A DEED OF TRUST DATED March 12, 2010. UNLESS YOU TAKE ACTION TO PROTECT YOUR PROPERTY, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDINGS AGAINST YOU, YOU SHOULD CONTACT A LAWYER. On August 10, 2016 at 10:30 AM, at the entrance to the East County Regional Center by statue, 250 E. Main Street, El Cajon, CA 92020, MTC Financial Inc. dba Trustee Corps, as the duly Appointed Trustee, under and pursuant to the power of sale contained in that certain Deed of Trust recorded on March 18, 2010, as Instrument No. 2010-0135291, of official records in the Office of the Recorder of San Diego County, California, executed by DAISY M LEWIS AN UNMARRIED WOMAN, as Trustor(s), in favor of MORTGAGE ELECTRONIC REGISTRATION SYSTEMS, INC. as nominee for FINANCIAL FREEDOM ACQUISITION LLC, A SUBSIDIARY OF ONEWEST BANK, FSB as Beneficiary, WILL SELL AT PUBLIC AUCTION TO THE HIGHEST BIDDER, in lawful money of the United States, all payable at the time of sale, that certain property situated in said County, California describing the land therein as: AS MORE FULLY DESCRIBED IN SAID DEED OF TRUST The property heretofore described is being sold “as is”. The street address and other common designation, if any, of the real property described above is purported to be: 268 GLOXINA STREET, ENCINTAS, CA 92024 The undersigned Trustee disclaims any liability for any incorrectness of the street address and other common designation, if any, shown herein. Said sale will be made without covenant or warranty, express or implied, regarding title, possession, or encumbrances, to pay the remaining principal sum of the Note(s) secured by said Deed of Trust, with interest thereon, as provided in said Note(s), advances if any, under the terms of the Deed of Trust, estimated fees, charges and expenses of the Trustee and of the trusts created by said Deed of Trust. The total amount of the unpaid balance of the obligations secured by the property to be sold and reasonable estimated costs, expenses and advances at the time of the initial publication of this Notice of Trustee’s Sale is estimated to be $364,338.65 (Estimated). However, prepayment premiums, accrued interest and advances will increase this figure prior to sale. Beneficiary’s bid at said sale may include all or part of said amount. In addition to cash, the Trustee will accept a cashier’s check drawn on a state or national bank, a check drawn by a state or federal credit union or a check drawn by a state or federal savings and loan association, savings association or savings bank specified in Section 5102 of the California Financial Code and authorized to do business in California, or other such funds as may be acceptable to the Trustee. In the event tender other than cash is accepted, the Trustee may withhold the issuance of the Trustee’s Deed Upon Sale until funds become available to the payee or endorsee as a matter of right. The property offered for sale excludes all funds held on account by the property receiver, if applicable. If the Trustee is unable to convey title for any reason, the successful bidder’s sole and exclusive remedy shall be the return of monies paid to the Trustee and the successful bidder shall have no further recourse. Notice to Potential Bidders If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a Trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a Trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same Lender may hold more than one mortgage or Deed of Trust on the property. Notice to Property Owner The sale date shown on this Notice of Sale may be postponed one or more times by the Mortgagee, Beneficiary, Trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about Trustee Sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sale date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call In Source Logic at 702-659-7766 for information regarding the Trustee’s Sale or visit the Internet Web site address listed below for information regarding the sale of this property, using the file number assigned to this case, CA07000299-16-1. Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. Date: May 27, 2016 MTC Financial Inc. dba Trustee Corps TS No. CA07000299-16-1 17100 Gillette Ave Irvine, CA 92614 949-252-8300 TDD: 866-660-4288 Miguel Ochoa, Authorized Signatory SALE INFORMATION CAN BE OBTAINED ON LINE AT www.insourcelogic.com FOR AUTOMATED SALES INFORMATION PLEASE CALL: In Source Logic AT 702-659-7766 MTC Financial Inc. dba Trustee Corps MAY BE ACTING AS A DEBT COLLECTOR ATTEMPTING TO COLLECT A DEBT. ANY INFORMATION OBTAINED MAY BE USED FOR THAT PURPOSE. ORDER NO. CA16-001907-1, PUB DATES: 06/10/2016, 06/17/2016, 06/24/2016 CN 18765
APN: 207-382-03-00 TS No: CA08000013-16-1 TO No: 5927121 NOTICE OF TRUSTEE’S SALE YOU ARE IN DEFAULT UNDER A DEED OF TRUST DATED July 13, 1998. UNLESS YOU TAKE ACTION TO PROTECT YOUR PROPERTY, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDINGS AGAINST YOU, YOU SHOULD CONTACT A LAWYER. On July 8, 2016 at 10:30 AM, at the entrance to the East County Regional Center by statue, 250 E. Main Street, El Cajon, CA 92020, MTC Financial Inc. dba Trustee Corps, as the duly Appointed Trustee, under and pursuant to the power of sale contained in that certain Deed of Trust recorded on July 22, 1998, as Instrument No. 1998-0457847, of official records in the Office of the Recorder of San Diego County, California, executed by LAURIE SENTENEY MASTEN, AN UNMARRIED WOMAN, as Trustor(s), in favor of WASHINGTON MUTUAL BANK, FA as Beneficiary, WILL SELL AT PUBLIC AUCTION TO THE HIGHEST BIDDER, in lawful money of the United States, all payable at the time of sale, that certain property situated in said County, California describing the land therein as: AS MORE FULLY DESCRIBED IN SAID DEED OF TRUST The property heretofore described is being sold “as is”. The street address and other common designation, if any, of the real property described above is purported to be: 1848 E. POINTE AVENUE, CARLSBAD, CA 92008 The undersigned Trustee disclaims any liability for any incorrectness of the street address and other common designation, if any, shown herein. Said sale will be made without covenant or warranty, express or implied, regarding title, possession, or encumbrances, to pay the remaining principal sum of the Note(s) secured by said Deed of Trust, with interest thereon, as provided in said Note(s), advances if any, under the terms of the Deed of Trust, estimated fees, charges and expenses of the Trustee and of the trusts created by said Deed of Trust. The total amount of the unpaid balance of the obligations secured by the property to be sold and reasonable estimated costs, expenses and advances at the time of the initial publication of this Notice of Trustee’s Sale is estimated to be $118,057.57 (Estimated). However, prepayment premiums, accrued interest and advances will increase this figure prior to sale. Beneficiary’s bid at said sale may include all or part of said amount. In addition to cash, the Trustee will accept a cashier’s check drawn on a state or national bank, a check drawn by a state or federal credit union or a check drawn by a state or federal savings and loan association, savings association or savings bank specified in Section 5102 of the California Financial Code and authorized to do business in California, or other such funds as may be acceptable to the Trustee. In the event tender other than cash is accepted, the Trustee may withhold the issuance of the Trustee’s Deed Upon Sale until funds become available to the payee or endorsee as a matter of right. The property offered for sale excludes all funds held on account by the property receiver, if applicable. If the Trustee is unable to convey title for any reason, the successful bidder’s sole and exclusive remedy shall be the return of monies paid to the Trustee and the successful bidder shall have no further recourse. Notice to Potential Bidders If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a Trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a Trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same Lender may hold more than one mortgage or Deed of Trust on the property. Notice to Property Owner The sale date shown on this Notice of Sale may be postponed one or more times by the Mortgagee, Beneficiary, Trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about Trustee Sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sale date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call In Source Logic at 702-659-7766 for information regarding the Trustee’s Sale or visit the Internet Web site address listed below for information regarding the sale of this property, using the file number assigned to this case, CA08000013-16-1. Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. Date: May 27, 2016 MTC Financial Inc. dba Trustee Corps TS No. CA08000013-16-1 17100 Gillette Ave Irvine, CA 92614 949-252-8300 TDD: 866-660-4288 Miguel Ochoa, Authorized Signatory SALE INFORMATION CAN BE OBTAINED ON LINE AT www.insourcelogic.com FOR AUTOMATED SALES INFORMATION PLEASE CALL: In Source Logic AT 702-659-7766 MTC Financial Inc. dba Trustee Corps MAY BE ACTING AS A DEBT COLLECTOR ATTEMPTING TO COLLECT A DEBT. ANY INFORMATION OBTAINED MAY BE USED FOR THAT PURPOSE. ORDER NO. CA16-001905-1, PUB DATES: 06/10/2016, 06/17/2016, 06/24/2016 CN 18764
APN: 161-421-23-00 TS No: CA05001467-15-2 TO No: 160015330-CA-DMI NOTICE OF TRUSTEE’S SALE YOU ARE IN DEFAULT UNDER A DEED OF TRUST DATED March 8, 2006. UNLESS YOU TAKE ACTION TO PROTECT YOUR PROPERTY, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDINGS AGAINST YOU, YOU SHOULD CONTACT A LAWYER. On August 10, 2016 at 10:30 AM, at the entrance to the East County Regional Center by statue, 250 E. Main Street, El Cajon, CA 92020, MTC Financial Inc. dba Trustee Corps, as the duly Appointed Trustee, under and pursuant to the power of sale contained in that certain Deed of Trust recorded on March 13, 2006, as Instrument No. 2006-0171943, of official records in the Office of the Recorder of San Diego County, California, executed by LEE OLIVER, JR., TRUSTEE OF THE LEE OLIVER, JR.SEPARATE TRUST DATED FEBRUARY 16, 2001, as Trustor(s), in favor of FINANCIAL FREEDOM SENIOR FUNDING CORPORATION, A SUBSIDIARY OF INDYMAC BANK, F.S.B. as Beneficiary, WILL SELL AT PUBLIC AUCTION TO THE HIGHEST BIDDER, in lawful money of the United States, all payable at the time of sale, that certain property situated in said County, California describing the land therein as: AS MORE FULLY DESCRIBED IN SAID DEED OF TRUST The property heretofore described is being sold “as is”. The street address and other common designation, if any, of the real property described above is purported to be: 4574 GOLDEN RIDGE DRIVE, OCEANSIDE , CA 92056 The undersigned Trustee disclaims any liability for any incorrectness of the street address and other common designation, if any, shown herein. Said sale will be made without covenant or warranty, express or implied, regarding title, possession, or encumbrances, to pay the remaining principal sum of the Note(s) secured by said Deed of Trust, with interest thereon, as provided in said Note(s), advances if any, under the terms of the Deed of Trust, estimated fees, charges and expenses of the Trustee and of the trusts created by said Deed of Trust. The total amount of the unpaid balance of the obligations secured by the property to be sold and reasonable estimated costs, expenses and advances at the time of the initial publication of this Notice of Trustee’s Sale is estimated to be $264,681.39 (Estimated). However, prepayment premiums, accrued interest and advances will increase this figure prior to sale. Beneficiary’s bid at said sale may include all or part of said amount. In addition to cash, the Trustee will accept a cashier’s check drawn on a state or national bank, a check drawn by a state or federal credit union or a check drawn by a state or federal savings and loan association, savings association or savings bank specified in Section 5102 of the California Financial Code and authorized to do business in California, or other such funds as may be acceptable to the Trustee. In the event tender other than cash is accepted, the Trustee may withhold the issuance of the Trustee’s Deed Upon Sale until funds become available to the payee or endorsee as a matter of right. The property offered for sale excludes all funds held on account by the property receiver, if applicable. If the Trustee is unable to convey title for any reason, the successful bidder’s sole and exclusive remedy shall be the return of monies paid to the Trustee and the successful bidder shall have no further recourse. Notice to Potential Bidders If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a Trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a Trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same Lender may hold more than one mortgage or Deed of Trust on the property. Notice to Property Owner The sale date shown on this Notice of Sale may be postponed one or more times by the Mortgagee, Beneficiary, Trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about Trustee Sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sale date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call In Source Logic at 702-659-7766 for information regarding the Trustee’s Sale or visit the Internet Web site address listed below for information regarding the sale of this property, using the file number assigned to this case, CA05001467-15-2. Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. Date: May 27, 2016 MTC Financial Inc. dba Trustee Corps TS No. CA05001467-15-2 17100 Gillette Ave Irvine, CA 92614 949-252-8300 TDD: 866-660-4288 Miguel Ochoa, Authorized Signatory SALE INFORMATION CAN BE OBTAINED ON LINE AT www.insourcelogic.com FOR AUTOMATED SALES INFORMATION PLEASE CALL: In Source Logic AT 702-659-7766 MTC Financial Inc. dba Trustee Corps MAY BE ACTING AS A DEBT COLLECTOR ATTEMPTING TO COLLECT A DEBT. ANY INFORMATION OBTAINED MAY BE USED FOR THAT PURPOSE. ORDER NO. CA16-001901-1, PUB DATES: 06/10/2016, 06/17/2016, 06/24/2016 CN 18763
T.S. No. 023516-CA APN: 214-640-28-00 NOTICE OF TRUSTEE’S SALE Pursuant to CA Civil Code 2923.3 IMPORTANT NOTICE TO PROPERTY OWNER: YOU ARE IN DEFAULT UNDER A DEED OF TRUST, DATED 1/29/2007. UNLESS YOU TAKE ACTION TO PROTECT YOUR PROPERTY, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDING AGAINST YOU, YOU SHOULD CONTACT A LAWYER On 6/27/2016 at 1:00 PM, CLEAR RECON CORP., as duly appointed trustee under and pursuant to Deed of Trust recorded 1/31/2007, as Instrument No. 2007-0068755, The subject Deed of Trust was modified by Loan Modification recorded as Instrument 2013-0624655 and recorded on 10/17/2013. of Official Records in the office of the County Recorder of San Diego County, State of CALIFORNIA executed by: CARMEN REBECCA NARANJO, A MARRIED WOMAN AS HER SOLE AND SEPARATE PROPERTY WILL SELL AT PUBLIC AUCTION TO HIGHEST BIDDER FOR CASH, CASHIER担 CHECK DRAWN ON A STATE OR NATIONAL BANK, A CHECK DRAWN BY A STATE OR FEDERAL CREDIT UNION, OR A CHECK DRAWN BY A STATE OR FEDERAL SAVINGS AND LOAN ASSOCIATION, SAVINGS ASSOCIATION, OR SAVINGS BANK SPECIFIED IN SECTION 5102 OF THE FINANCIAL CODE AND AUTHORIZED TO DO BUSINESS IN THIS STATE: OUTSIDE THE MAIN ENTRANCE AT THE SUPERIOR COURT NORTH COUNTY DIVISION, 325 S MELROSE DR., VISTA, CA 92081 all right, title and interest conveyed to and now held by it under said Deed of Trust in the property situated in said County and State described as: MORE FULLY DESCRIBED ON SAID DEED OF TRUST The street address and other common designation, if any, of the real property described above is purported to be: 7042 HERON CIRCLE CARLSBAD, CA 92011 The undersigned Trustee disclaims any liability for any incorrectness of the street address and other common designation, if any, shown herein. Said sale will be held, but without covenant or warranty, express or implied, regarding title, possession, condition, or encumbrances, including fees, charges and expenses of the Trustee and of the trusts created by said Deed of Trust, to pay the remaining principal sums of the note(s) secured by said Deed of Trust. The total amount of the unpaid balance of the obligation secured by the property to be sold and reasonable estimated costs, expenses and advances at the time of the initial publication of the Notice of Sale is: $1,216,144.81 If the Trustee is unable to convey title for any reason, the successful bidder’s sole and exclusive remedy shall be the return of monies paid to the Trustee, and the successful bidder shall have no further recourse. The beneficiary under said Deed of Trust heretofore executed and delivered to the undersigned a written Declaration of Default and Demand for Sale, and a written Notice of Default and Election to Sell. The undersigned caused said Notice of Default and Election to Sell to be recorded in the county where the real property is located. NOTICE TO POTENTIAL BIDDERS: If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same lender may hold more than one mortgage or deed of trust on the property. NOTICE TO PROPERTY OWNER: The sale date shown on this notice of sale may be postponed one or more times by the mortgagee, beneficiary, trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about trustee sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sale date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call (844) 477-7869 or visit this Internet Web site WWW.STOXPOSTING.COM, using the file number assigned to this case 023516-CA. Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. FOR SALES INFORMATION: (844) 477-7869 CLEAR RECON CORP. 4375 Jutland Drive Suite 200 San Diego, California 92117 06/03/16, 06/10/16, 06/17/16 CN 18741
T.S. No. 030200-CA APN: 161-601-57-00 NOTICE OF TRUSTEE’S SALE Pursuant to CA Civil Code 2923.3 IMPORTANT NOTICE TO PROPERTY OWNER: YOU ARE IN DEFAULT UNDER A DEED OF TRUST, DATED 2/17/2005. UNLESS YOU TAKE ACTION TO PROTECT YOUR PROPERTY, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDING AGAINST YOU, YOU SHOULD CONTACT A LAWYER On 6/27/2016 at 1:00 PM, CLEAR RECON CORP., as duly appointed trustee under and pursuant to Deed of Trust recorded 3/1/2005, as Instrument No. 2005-0166128, of Official Records in the office of the County Recorder of San Diego County, State of CALIFORNIA executed by: RONALD BARBOZA, AN UNMARRIED MAN AND AUDRA A WELLS, A SINGLE WOMAN, AS JOINT TENANTS WILL SELL AT PUBLIC AUCTION TO HIGHEST BIDDER FOR CASH, CASHIER’S CHECK DRAWN ON A STATE OR NATIONAL BANK, A CHECK DRAWN BY A STATE OR FEDERAL CREDIT UNION, OR A CHECK DRAWN BY A STATE OR FEDERAL SAVINGS AND LOAN ASSOCIATION, SAVINGS ASSOCIATION, OR SAVINGS BANK SPECIFIED IN SECTION 5102 OF THE FINANCIAL CODE AND AUTHORIZED TO DO BUSINESS IN THIS STATE: OUTSIDE THE MAIN ENTRANCE AT THE SUPERIOR COURT NORTH COUNTY DIVISION, 325 S MELROSE DR., VISTA, CA 92081 all right, title and interest conveyed to and now held by it under said Deed of Trust in the property situated in said County and State described as: Lot 57 of Rancho Del Oro Village I, Tract 1.3, in the City of Oceanside, County of San Diego, State of California, according to Map thereof No. 11793, filed in the Office of the County Recorder of San Diego County on April 22, 1987. The street address and other common designation, if any, of the real property described above is purported to be: 1751 CALLE PLATICO OCEANSIDE, CA 92056 The undersigned Trustee disclaims any liability for any incorrectness of the street address and other common designation, if any, shown herein. Said sale will be held, but without covenant or warranty, express or implied, regarding title, possession, condition, or encumbrances, including fees, charges and expenses of the Trustee and of the trusts created by said Deed of Trust, to pay the remaining principal sums of the note(s) secured by said Deed of Trust. The total amount of the unpaid balance of the obligation secured by the property to be sold and reasonable estimated costs, expenses and advances at the time of the initial publication of the Notice of Sale is: $551,514.84 If the Trustee is unable to convey title for any reason, the successful bidder’s sole and exclusive remedy shall be the return of monies paid to the Trustee, and the successful bidder shall have no further recourse. The beneficiary under said Deed of Trust heretofore executed and delivered to the undersigned a written Declaration of Default and Demand for Sale, and a written Notice of Default and Election to Sell. The undersigned caused said Notice of Default and Election to Sell to be recorded in the county where the real property is located. NOTICE TO POTENTIAL BIDDERS: If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same lender may hold more than one mortgage or deed of trust on the property. NOTICE TO PROPERTY OWNER: The sale date shown on this notice of sale may be postponed one or more times by the mortgagee, beneficiary, trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about trustee sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sale date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call (844) 477-7869 or visit this Internet Web site WWW.STOXPOSTING.COM, using the file number assigned to this case 030200-CA. Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. FOR SALES INFORMATION: (844) 477-7869 CLEAR RECON CORP. 4375 Jutland Drive Suite 200 San Diego, California 92117 06/03/16, 06/10/16, 06/17/16 CN 18738
APN: 205-060-70-00 TS No: CA01000332-13 TO No: 95303682 NOTICE OF TRUSTEE’S SALE YOU ARE IN DEFAULT UNDER A DEED OF TRUST DATED May 3, 2007. UNLESS YOU TAKE ACTION TO PROTECT YOUR PROPERTY, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDINGS AGAINST YOU, YOU SHOULD CONTACT A LAWYER. On June 24, 2016 at 10:30 AM, at the entrance to the East County Regional Center by statue, 250 E. Main Street, El Cajon, CA 92020, Special Default Services, Inc., as the duly Appointed Trustee, under and pursuant to the power of sale contained in that certain Deed of Trust Recorded on May 11, 2007 as Instrument No. 2007-0321929 of official records in the Office of the Recorder of San Diego County, California, executed by STEPHEN E SHAW AND KIMBERLY J SHAW, HUSBAND AND WIFE AS JOINT TENA, as Trustor(s), in favor of NATIONAL CITY BANK as Beneficiary, WILL SELL AT PUBLIC AUCTION TO THE HIGHEST BIDDER, in lawful money of the United States, all payable at the time of sale, that certain property situated in said County, California describing the land therein as: AS MORE FULLY DESCRIBED IN SAID DEED OF TRUST The property heretofore described is being sold “as is”. The street address and other common designation, if any, of the real property described above is purported to be: 3285 JAMES DR , CARLSBAD, CA 92008. The undersigned Trustee disclaims any liability for any incorrectness of the street address and other common designation, if any, shown herein. Said sale will be made without covenant or warranty, express or implied, regarding title, possession, or encumbrances, to pay the remaining principal sum of the Note(s) secured by said Deed of Trust, with interest thereon, as provided in said Note(s), advances if any, under the terms of the Deed of Trust, estimated fees, charges and expenses of the Trustee and of the trusts created by said Deed of Trust. The total amount of the unpaid balance of the obligations secured by the property to be sold and reasonable estimated costs, expenses and advances at the time of the initial publication of this Notice of Trustee’s Sale is estimated to be $170,074.86 (Estimated). However, prepayment premiums, accrued interest and advances will increase this figure prior to sale. Beneficiary’s bid at said sale may include all or part of said amount. In addition to cash, the Trustee will accept a cashier’s check drawn on a state or national bank, a check drawn by a state or federal credit union or a check drawn by a state or federal savings and loan association, savings association or savings bank specified in Section 5102 of the California Financial Code and authorized to do business in California, or other such funds as may be acceptable to the Trustee. In the event tender other than cash is accepted, the Trustee may withhold the issuance of the Trustee’s Deed Upon Sale until funds become available to the payee or endorsee as a matter of right. The property offered for sale excludes all funds held on account by the property receiver, if applicable. If the Trustee is unable to convey title for any reason, the successful bidder’s sole and exclusive remedy shall be the return of monies paid to the Trustee and the successful bidder shall have no further recourse. Notice to Potential Bidders If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a Trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a Trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same Lender may hold more than one mortgage or Deed of Trust on the property. Notice to Property Owner The sale date shown on this Notice of Sale may be postponed one or more times by the Mortgagee, Beneficiary, Trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about Trustee Sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sale date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call In Source Logic AT 702-659-7766 for information regarding the Special Default Services, Inc. or visit the Internet Web site address listed below for information regarding the sale of this property, using the file number assigned to this case, CA01000332-13. Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. Date: May 24, 2016 Special Default Services, Inc. TS No. CA01000332-13 17100 Gillette Ave Irvine, CA 92614 (844) 706-4182 TDD: 866-660-4288 Lisa Rohrbacker, Trustee Sales Officer SALE INFORMATION CAN BE OBTAINED ON LINE AT www.insourcelogic.com FOR AUTOMATED SALES INFORMATION PLEASE CALL: In Source Logic AT 702-659-7766 SPECIAL DEFAULT SERVICES, INC. MAY BE ACTING AS A DEBT COLLECTOR ATTEMPTING TO COLLECT A DEBT. ANY INFORMATION OBTAINED MAY BE USED FOR THAT PURPOSE. ORDER NO. CA16-001804-1, PUB DATES: 06/03/2016, 06/10/2016, 06/17/2016 CN 18737
T.S. No. 16-41362 APN: 158-190-31-67 Loan Number: 0227749 NOTICE OF TRUSTEE’S SALE YOU ARE IN DEFAULT UNDER A DEED OF TRUST DATED 12/14/2006. UNLESS YOU TAKE ACTION TO PROTECT YOUR PROPERTY, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDING AGAINST YOU, YOU SHOULD CONTACT A LAWYER. A public auction sale to the highest bidder for cash, cashier’s check drawn on a state or national bank, check drawn by a state or federal credit union, or a check drawn by a state or federal savings and loan association, or savings association, or savings bank specified in Section 5102 of the Financial Code and authorized to do business in this state will be held by the duly appointed trustee as shown below, of all right, title, and interest conveyed to and now held by the trustee in the hereinafter described property under and pursuant to a Deed of Trust described below. The sale will be made, but without covenant or warranty, expressed or implied, regarding title, possession, or encumbrances, to pay the remaining principal sum of the note(s) secured by the Deed of Trust, with interest and late charges thereon, as provided in the note(s), advances, under the terms of the Deed of Trust, interest thereon, fees, charges and expenses of the Trustee for the total amount (at the time of the initial publication of the Notice of Sale) reasonably estimated to be set forth below. The amount may be greater on the day of sale. Trustor: MARIA L. LOAIZA, A SINGLE WOMAN Duly Appointed Trustee: LAW OFFICES OF LES ZIEVE Deed of Trust recorded 12/20/2006 as Instrument No. 2006-0903241 in book , page of Official Records in the office of the Recorder of San Diego County, California, Date of Sale:6/27/2016 at 10:30 AM Place of Sale: AT THE ENTRANCE TO THE EAST COUNTY REGIONAL CENTER BY STATUE, 250 E. MAIN STREET, EL CAJON, CA 92020 Estimated amount of unpaid balance and other charges: $188,498.90 Note: Because the Beneficiary reserves the right to bid less than the total debt owed, it is possible that at the time of the sale the opening bid may be less than the total debt owed. Street Address or other common designation of real property: 3571 Guava Way Oceanside, CA 92058-1676 Described as follows: AS MORE FULLY DESCRIBED ON SAID DEED OF TRUST A.P.N #.: 158-190-31-67 The undersigned Trustee disclaims any liability for any incorrectness of the street address or other common designation, if any, shown above. If no street address or other common designation is shown, directions to the location of the property may be obtained by sending a written request to the beneficiary within 10 days of the date of first publication of this Notice of Sale. NOTICE TO POTENTIAL BIDDERS: If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same lender may hold more than one mortgage or deed of trust on the property. NOTICE TO PROPERTY OWNER: The sale date shown on this notice of sale may be postponed one or more times by the mortgagee, beneficiary, trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about trustee sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sale date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call (714) 848-9272 or or visit this Internet Web site www.elitepostandpub.com, using the file number assigned to this case 16-41362. Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. Dated: 5/23/2016 Law Offices of Les Zieve, as Trustee 30 Corporate Park, Suite 450 Irvine, CA 92606 For Non-Automated Sale Information, call: (714) 848-7920 For Sale Information: (714) 848-9272 or www.elitepostandpub.com Melanie Schultz, Trustee Sale Officer THIS FIRM IS ATTEMPTING TO COLLECT A DEBT AND ANY INFORMATION WE OBTAINED WILL BE USED FOR THAT PURPOSE. EPP 17918 6/3, 6/10, 6/17/16 CN 18736
LIEN SALE Notice is hereby given that pursuant to Section 21701-2171 of the business and Professions Code, Section 2382 of the Commercial Code, Section 535 of the Penal Code, Solana Beach Storage, 545 Stevens Ave, Solana Beach, CA., 92075 will sell by competitive bidding 7/03/16. Auction to be held online at www.storagetreasures.com, beginning on 07/01/16. Property to be sold as follows: miscellaneous household goods, personal items, furniture, and clothing belonging to the following: 689 Maria Flores 117 Christine Infante 8184 Christine Infante 8185 Christine Infante 1112 Christine Infante
635 Christine Infante 8069 Christine Infante 426 Christine Infante 7771 Christine Infante 538 Christine Infante 534 Christine Infante 615 Stephanie Neville 6/17, 6/24/16 CNS-2892992# CN 18814
SUPERIOR COURT OF CALIFORNIA, COUNTY OF SAN DIEGO in re: THE JOHN A. ORLANDO AND JOANN J. ORLANDO TRUST AGREEMENT DATED FEBRUARY 22, 1989 BY: JOHN A. ORLANDO, Decedent NOTICE TO CREDITORS (Cal. Probate Code § 19050) Notice is hereby given to the creditors and contingent creditors of the above-named decedent that all persons having claims against the decedent are required to mail or deliver a copy to JOANN J. ORLANDO, Trustee of The John A. Orlando and Joann J. Orlando Trust Agreement Dated February 22, 1989 of which the Decedent was the grantor, c/o BRENDA GEIGER, Attorney at Law, at 1917 Palomar Oaks Way, Suite 160, Carlsbad, CA 92008, within the later of 4 months after date of first publication of notice to creditors or, if notice is mailed or personally delivered to you, 60 days after the date this notice is mailed or personally delivered to you, or you must petition to file a late claim as provided in Probate Code §19103. A claim form may be obtained from the court clerk. For your protection, you are encouraged to file your claim by certified mail, with return receipt requested. Date: June 10, 2016 /s/ BRENDA GEIGER, Attorney at Law Attorney for Trustee, Joann J. Orlando Pub. … 2016 Geiger Law Office, P.C. 1917 Palomar Oaks Way, Suite 160 Carlsbad, CA 92008 (760) 448-2220 06/17/16, 06/24/16, 07/01/16 CN 18795
SUMMONS (Family Law) CITACION (Derecho familiar) CASE NUMBER (NUMERO DE CASO) DN186281 NOTICE TO RESPONDENT AVISO AL DEMANDADO: Maricy Vieira Infante You are being sued. Read the information below and on the next page. Lo han demandando. Lea la informacion a continuacion y en la pagina siguiente. Petitioner’s Name is: Nombre del demandante: Robert A. Paul. You have 30 calendar days after this Summons and Petition are served on you to file a Response (form FL-120 or FL-123) at the court and have a copy served on the petitioner. A letter, phone call, or court appearance will not protect you. If you do not file your Response on time, the court may make orders affecting your marriage or domestic partnership, your property, and custody of your children. You may be ordered to pay support and attorney fees and costs. For legal advice, contact a lawyer immediately. Get help finding a lawyer at the California Courts Online Self-Help Center (www.courts.ca.gov/selfhelp), at the California Legal Services website (www.lawhelpca.org), or by contacting your local county bar association. Tiene 30 dias de calendario despues de haber recibido la entrega legal de esta Citacion y Peticion para presentar una Respuesta (fomulario FL-120 o FL-123) ante la corte y efectuar la entrega legal de una copia al demandante. Una carta o llamada telefonica o una audiencia de la corte no basta para protegerio.
Si no presenta su Respuesta a tiempo, la corte puede dar ordenes que afecten su matrimonio o pareja de hecho, sus bienes y la custodia de sus hijos. La corte tambien le puede ordenar que pague manutencion, y honorarios y costos legales. Para asesoramiento legal, pongase en contacto de inmediato con un abogado. Puede abtener informacion para encontrar un abogado en el Centro de Ayuda de las Cortes de California (www.sucorte.ca.gov) en el sitio web de lost Servicios Legales de California (www.lawhelpca.org) o poniendose en contacto con el colegio de abogados de su condado.
NOTICE-RESTRAINING ORDERS ARE: These restraining orders are effective against both spouses or domestic partners until the petition is dismissed, a judgment is entered, or the court makes further orders. They are enforceable anywhere in California by any law enforcement officer who has received or seen a copy of them. AVISO-LAS ORDENES DE RESTRICCION: Las ordenes de restriccion estan en vigencia en cuanto a ambos conyuges o miembros de la pareja de hecho hasta que se despida la peticion, se emita un fallo o la corte de otras ordenes. Cualquier agencia del orden publico que haya recibido o visto una copia de estas ordenes puede hacerlas acatar en cualquier lugar de California. FEE WAIVER: If you cannot pay the filing fee, ask the clerk for a fee waiver form. The court may order you to pay back all or part of the fees and costs that the court waived for you or the other party. EXENCION DE CUOTAS: Si no puede pagar la cuota de presentacion, pida al secretario un formulario de exencion de cuotas. La corte puede ordenar que usted pague, ya sea en parte o por completo, las cuotas y costos de la corte previamente exentos a peticion de usted o de la otra parte. The name and address of the court are (El nombre y direccion de la corte son): San Diego Superior Court North County Division 325 S Melrose Dr Vista CA 92081 The name, address, and telephone number of petitioner’s attorney, or petitioner without an attorney, are: (El nombre, direccion y numero de telefono del abogado del demandante, o del demandante si no tiene abogado, son): Susan L. Schnepf SBN #137901 2214 Faraday Ave Carlsbad CA 92008 Telephone: 760.753.5357 Date (Fecha): 02/29/16 Clerk, by (Secretario, por), S. Miranda Deputy (Asistente) NOTICE OF CASE ASSIGNMENT, HEARING, DECLARATION OF DISCLOSURE CASE # CN186281 Judicial Officer: Michael D. Washington Department: N-18 Phone: 760.201.8095 Complaint Filed: 02/29/16 Notice is given that the above-entitled case has been set for the reason listed below and at the location shown above. Family Resolution Conferennce DATE 08/05/16 TIME 8:30 AM DEPT N-18 Judge Michael D. Washington NOTICE TO THE PERSON SERVED: You are served as an individual defendant 06/17, 06/24, 07/01, 07/08/16 CN 18794
NOTICE OF PETITION TO ADMINISTER ESTATE OF ALETA CATHERINE RIETTA CASE # 37-2016-00018544-PR-LA-CTL To all heirs, beneficiaries, creditors, contingent creditors, and persons who may otherwise be interested in the will or estate, or both, of: Aleta Rietta, aka Aleta C. Rietta. A Petition for Probate has been filed by Kathleen Rietta Wong in the Superior Court of California, County of San Diego. The Petition for Probate requests that Kathleen Rietta Wong be appointed as personal representative to administer the estate of the decedent. The petition requests authority to administer the estate under the Independent Administration of Estates Act. (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority.
A hearing on the petition will be held in this court on July 7, 2016 at 1:30 PM in Dept. PC-3 located at 1409 Fourth Ave, San Diego, CA 92101 Madge Bradley Building. If you object to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney. If you are a creditor or a contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law. You may examine the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk. Petitioner: Kathleen Rietta Wong 19230 Carlton Ave Castro Valley CA 94546 Telephone: 775.741.9555 06/10, 06/17, 06/24/16 CN 18774
SUMMONS (Family Law) CITACION (Derecho familiar) CASE NUMBER (NUMERO DE CASO) DN186884 NOTICE TO RESPONDENT AVISO AL DEMANDADO: Bernarda Revero Barrientos You are being sued. Read the information below and on the next page. Lo han demandando. Lea la informacion a continuacion y en la pagina siguiente. Petitioner’s Name is: Nombre del demandante: Salvador Mendiola Barrientos Jr. You have 30 calendar days after this Summons and Petition are served on you to file a Response (form FL-120 or FL-123) at the court and have a copy served on the petitioner. A letter, phone call, or court appearance will not protect you. If you do not file your Response on time, the court may make orders affecting your marriage or domestic partnership, your property, and custody of your children. You may be ordered to pay support and attorney fees and costs. For legal advice, contact a lawyer immediately. Get help finding a lawyer at the California Courts Online Self-Help Center (www.courts.ca.gov/selfhelp), at the California Legal Services website (www.lawhelpca.org), or by contacting your local county bar association. Tiene 30 dias de calendario despues de haber recibido la entrega legal de esta Citacion y Peticion para presentar una Respuesta (fomulario FL-120 o FL-123) ante la corte y efectuar la entrega legal de una copia al demandante. Una carta o llamada telefonica o una audiencia de la corte no basta para protegerio. Si no presenta su Respuesta a tiempo, la corte puede dar ordenes que afecten su matrimonio o pareja de hecho, sus bienes y la custodia de sus hijos. La corte tambien le puede ordenar que pague manutencion, y honorarios y costos legales. Para asesoramiento legal, pongase en contacto de inmediato con un abogado. Puede abtener informacion para encontrar un abogado en el Centro de Ayuda de las Cortes de California (www.sucorte.ca.gov) en el sitio web de lost Servicios Legales de California (www.lawhelpca.org) o poniendose en contacto con el colegio de abogados de su condado. NOTICE-RESTRAINING ORDERS ARE: These restraining orders are effective against both spouses or domestic partners until the petition is dismissed, a judgment is entered, or the court makes further orders. They are enforceable anywhere in California by any law enforcement officer who has received or seen a copy of them. AVISO-LAS ORDENES DE RESTRICCION: Las ordenes de restriccion estan en vigencia en cuanto a ambos conyuges o miembros de la pareja de hecho hasta que se despida la peticion, se emita un fallo o la corte de otras ordenes. Cualquier agencia del orden publico que haya recibido o visto una copia de estas ordenes puede hacerlas acatar en cualquier lugar de California. FEE WAIVER: If you cannot pay the filing fee, ask the clerk for a fee waiver form. The court may order you to pay back all or part of the fees and costs that the court waived for you or the other party. EXENCION DE CUOTAS: Si no puede pagar la cuota de presentacion, pida al secretario un formulario de exencion de cuotas. La corte puede ordenar que usted pague, ya sea en parte o por completo, las cuotas y costos de la corte previamente exentos a peticion de usted o de la otra parte. The name and address of the court are (El nombre y direccion de la corte son): San Diego Superior Court North County Division 325 S Melrose Dr Vista CA 92081 The name, address, and telephone number of petitioner’s attorney, or petitioner without an attorney, are: (El nombre, direccion y numero de telefono del abogado del demandante, o del demandante si no tiene abogado, son): Salvador Mendiola Barrientos Jr. 805 Red Blush Rd Escondido CA 92027 Telephone: 760.975-3159 Date (Fecha): 04/19/16 Clerk, by (Secretario, por), L. Fita=-Sialoi Deputy (Asistente) NOTICE TO THE PERSON SERVED: You are served as an individual defendant. 06/10, 06/17, 06/24, 07/01/16 CN 18770
NOTICE OF PETITION TO ADMINISTER ESTATE OF BEVERLY JEAN PETERSON CASE# 37-2016-00018011-PR-PL-CTL To all heirs, beneficiaries, creditors, contingent creditors, and persons who may otherwise be interested in the will or estate, or both, of Beverly Jean Peterson, aka Beverly Jean Handler, aka Beverly Jean Collins. A Petition for Probate has been filed by Linda G. Seale in the Superior Court of California, County of San Diego. The Petition for Probate requests that Linda G. Seale be appointed as personal representative to administer the estate of the decedent. The petition requests the decedent’s will and codicils, if any, be admitted to probate. The will and any codicils are available for examination in the file kept by the court. The petition requests authority to administer the estate under the Independent Administration of Estates Act. (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority. A hearing on the petition will be held in this court on July 21, 2016 at 1:30 PM in Dept. PC-2 located at 1409 Fourth Ave, San Diego, CA 92101 Madge Bradley Building. If you object to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney. If you are a creditor or a contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law. You may examine the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk. Attorney for Petitioner: Arasto Farsad Farsad Law Office, PC 2905 Stender Way #76 Santa Clara CA 95054 Telephone: 408.641.9966 06/03, 06/10, 06/17/16 CN 18749
NOTICE OF PETITION TO ADMINISTER ESTATE OF JAYNE A. GUDMUNDSSON CASE# 37-2016-00012205-PR-PW-CTL To all heirs, beneficiaries, creditors, contingent creditors, and persons who may otherwise be interested in the will or estate, or both, of Jayne A. Gudmundsson. A Petition for Probate has been filed by Robert J. Winters in the Superior Court of California, County of San Diego. The Petition for Probate requests that Robert J. Winters be appointed as personal representative to administer the estate of the decedent. The petition requests the decedent’s will and codicils, if any, be admitted to probate. The will and any codicils are available for examination in the file kept by the court. The petition requests authority to administer the estate under the Independent Administration of Estates Act. (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority. A hearing on the petition will be held in this court on Jun 21, 2016 at 11:00 AM in Dept. PC-1 located at 1409 Fourth Ave, San Diego, CA 92101 Madge Bradley Building. If you object to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney. If you are a creditor or a contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law. You may examine the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk. Petitioner: Robert J. Winters 437 Grant St, 14th Floor Pittsburgh PA 15219 Telephone: 412.281.0587 06/03, 06/10, 06/17/16 CN 18748
ORDER TO SHOW CAUSE FOR CHANGE OF NAME CASE# 37-2016-00017087-CU-PT-NC TO ALL INTERESTED PERSONS: Petitioner(s): Micah Andrew Gillespie filed a petition with this court for a decree changing name as follows: a. Present name: Micah Andrew Gillespie change to proposed name: Micah Andrew Steigerwald. THE COURT ORDERS that all persons interested in this matter appear before this Court at the hearing indicated below to show cause, if any, why the petition for a change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing. NOTICE OF HEARING: On July 12, 2016 at 8:30 a.m., in Dept 26 of the Superior Court of California, 325 S Melrose Dr, Vista CA 92081, North County Regional Division. Date: May 23, 2016 William S Dato Judge of the Superior Court 06/03, 06/10, 06/17, 06/24/16 CN 18743
SUMMONS (Family Law) CITACION (Derecho familiar) CASE NUMBER (NUMERO DE CASO) DN187100 NOTICE TO RESPONDENT AVISO AL DEMANDADO: Maria Chemriak You are being sued. Read the information below and on the next page. Lo han demandando. Lea la informacion a continuacion y en la pagina siguiente. Petitioner’s Name is: Nombre del demandante: Marcos Trejo You have 30 calendar days after this Summons and Petition are served on you to file a Response (form FL-120 or FL-123) at the court and have a copy served on the petitioner. A letter, phone call, or court appearance will not protect you. If you do not file your Response on time, the court may make orders affecting your marriage or domestic partnership, your property, and custody of your children. You may be ordered to pay support and attorney fees and costs. For legal advice, contact a lawyer immediately. Get help finding a lawyer at the California Courts Online Self-Help Center (www.courts.ca.gov/selfhelp), at the California Legal Services website (www.lawhelpca.org), or by contacting your local county bar association. Tiene 30 dias de calendario despues de haber recibido la entrega legal de esta Citacion y Peticion para presentar una Respuesta (fomulario FL-120 o FL-123) ante la corte y efectuar la entrega legal de una copia al demandante. Una carta o llamada telefonica o una audiencia de la corte no basta para protegerio. Si no presenta su Respuesta a tiempo, la corte puede dar ordenes que afecten su matrimonio o pareja de hecho, sus bienes y la custodia de sus hijos. La corte tambien le puede ordenar que pague manutencion, y honorarios y costos legales. Para asesoramiento legal, pongase en contacto de inmediato con un abogado. Puede abtener informacion para encontrar un abogado en el Centro de Ayuda de las Cortes de California (www.sucorte.ca.gov) en el sitio web de lost Servicios Legales de California (www.lawhelpca.org) o poniendose en contacto con el colegio de abogados de su condado. NOTICE-RESTRAINING ORDERS ARE: These restraining orders are effective against both spouses or domestic partners until the petition is dismissed, a judgment is entered, or the court makes further orders. They are enforceable anywhere in California by any law enforcement officer who has received or seen a copy of them. AVISO-LAS ORDENES DE RESTRICCION: Las ordenes de restriccion estan en vigencia en cuanto a ambos conyuges o miembros de la pareja de hecho hasta que se despida la peticion, se emita un fallo o la corte de otras ordenes. Cualquier agencia del orden publico que haya recibido o visto una copia de estas ordenes puede hacerlas acatar en cualquier lugar de California. FEE WAIVER: If you cannot pay the filing fee, ask the clerk for a fee waiver form. The court may order you to pay back all or part of the fees and costs that the court waived for you or the other party. EXENCION DE CUOTAS: Si no puede pagar la cuota de presentacion, pida al secretario un formulario de exencion de cuotas. La corte puede ordenar que usted pague, ya sea en parte o por completo, las cuotas y costos de la corte previamente exentos a peticion de usted o de la otra parte. The name and address of the court are (El nombre y direccion de la corte son): San Diego Superior Court North County Division 325 S Melrose Dr Vista CA 92081 The name, address, and telephone number of petitioner’s attorney, or petitioner without an attorney, are: (El nombre, direccion y numero de telefono del abogado del demandante, o del demandante si no tiene abogado, son): Marcos Trejo 2609 Meadow Ln Escondido CA 92027 Telephone: 760.975-7198 Date (Fecha): 05/20/16 Clerk, by (Secretario, por), Y. Valdez Deputy (Asistente) NOTICE TO THE PERSON SERVED: You are served as an individual defendant. 06/03, 06/10, 06/17, 06/24/16 CN 18742
NOTICE OF PETITION TO ADMINISTER ESTATE OF CLAUDIA LOUISE STINE CASE # 37-2016-00016503-PR-LA-CTL ROA #1 To all heirs, beneficiaries, creditors, contingent creditors, and persons who may otherwise be interested in the will or estate, or both, of: Claudia Louise Stine A Petition for Probate has been filed by Kathleen S. Hixon in the Superior Court of California, County of San Diego. The Petition for Probate requests that Kathleen S. Hixon be appointed as personal representative to administer the estate of the decedent. The petition requests authority to administer the estate under the Independent Administration of Estates Act. (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority. A hearing on the petition will be held in this court on July 21, 2016 at 1:30 PM in Dept. PC-2 located at 1409 Fourth Ave, San Diego, CA 92101 Madge Bradley Building. If you object to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney. If you are a creditor or a contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law. You may examine the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk. Attorney for Petitioner: Sarah S. Nix 279 Front St. Danville CA 94526 Telephone: 925.837.0585 06/03, 06/10, 06/17/16 CN 18740
SUMMONS (CITACION JUDICIAL) CASE #:37-2015-00033549-CU-BC-NC NOTICE TO DEFENDANT: (AVISO AL DEMANDADO): MARK MARIANI YOU ARE BEING SUED BY PLAINTIFF: (LO ESTA DEMANDANDO EL DEMANDANTE): YURIY BUZCKO NOTICE! You have been sued. The court may decide against you without your being heard unless you respond within 30 days. Read the information below. You have 30 CALENDAR DAYS after this summons and legal papers are served on you to file a written response at this court and have a copy served on the plaintiff. A letter or phone call will not protect you. Your written response must be in proper legal form if you want the court to hear your case. There may be a court form that you can use for your response. You can find these court forms and more information at the California Courts Online Self-Help Center (www.courtinfo.ca.gov/selfhelp), your county law library, or the courthouse nearest you. If you cannot pay the filing fee, ask the court clerk for a fee waiver form. If you do not file your response on time, you may lose the case by default, and your wages, money, and property may be taken without further warning from the court. There are other legal requirements. You may want to call an attorney right away. If you do not know an attorney, you may want to call an attorney referral service. If you cannot afford an attorney, you may be eligible for free legal services from a nonprofit legal services program. You can locate these nonprofit groups at the California Legal Services Web site (www.lawhelpcalifornia.org), the California Courts Online Self-Help Center (www.courtinfo.ca.gov/selfhelp), or by contacting your local court or county bar association. NOTE: The court has a statutory lien for waived fees and costs on any settlement or arbitration award of $10,000 or more in a civil. case. The court’s lien must be paid before the court will dismiss the case. AVISO! Lo han demandado. Si no responde dentro de 30 dias, la corte puede decidir en su contra sin escuchar su version. Lea la informacion a continuacion. Tiene 30 DIAS DE CALENDARIO despues de que le entreguen esta citacion y papeles legales para presentar una respuesta por escrito en esta corte y hacer que se entregue una copia al demandante. Una carta o una llamada telefonica no lo protegen. Su respuesta por escrito tiene que estar en formato legal correcto si desea que procesen su caso en la corte. Es posible que haya un formulario que usted pueda usar para su respuesta.Puede encontrar estos formularios de la corte y mas informacion en el Centro de Ayuda de las Cortes de California (www.sucorte.ca.gov), en la biblioteca de leyes de su condado o en la corte que le quede mas cerca. Si no puede pagar la cuota de presentacion, pida al secretario de la corte que le de un formulario de exencion de pago de cuotas. Si no presenta su respuesta a tiempo, puede perder el caso por incumplimiento y la corte le podra quitar su sueldo, dinero y bienes sin mas advertencia. Hay otros requisitos legales. Es recomendable que llame a un abogado inmediatamente. Si no conoce a un abogado, puede llamar a un servicio de remision a abogados. Si no puede pagar a un abogado, es posible que cumpla con los requisitos para obtener servicios legales gratuitos de un programa de servicios legales sin fines de lucro. Puede encontrar estos grupos sin fines de lucro en el sitio web de California Legal Services, (www.lawhelpcalifornia.org), en el Centro de Ayuda de las Cortes de California, (www.sucorte.ca.gov) o poniendose en contacto con la corte o el colegio de abogados locales. AVISO: Por ley, la corte tiene derecho a reclamar las cuotas y los costos exentos por imponer un gravamen sobre cualquier recuperacion de $10,000 o mas de valor recibida mediante un acuerdo o una concesion de arbitraje en un caso de derecho civil. Tiene que pagar el gravamen de la corte antes de que la corte pueda desechar el caso. The name and address of the court is: (El nombre y direccion de la corte es): Superior Court for the County of San Diego – North County, 325 S Melrose Dr., Vista CA 92081 The name, address, and telephone number of plaintiff’s attorney, or plaintiff without an attorney, is: (El nombre, la direccion y el numero de telefono del abogado del demandante, o del demandante que no tiene abogado, es): Evan Dwin – Dwin Legal, PAC 2141 Palomar Airport Rd #320 Telephone: 760.536.6471 Date: (Fecha), 10/22/15 Clerk, by (Secretario) V. Navarro, Deputy Adjunto) NOTICE TO THE PERSON SERVED: You are served as an individual defendant. 06/03, 06/10, 06/17, 06/24/16
CN 18739
ORDER TO SHOW CAUSE FOR CHANGE OF NAME CASE# 37-2016-00016201-CU-PT-CTL TO ALL INTERESTED PERSONS: Petitioner(s): Amanda Bobczynski on behalf of minor filed a petition with this court for a decree changing names as follows: a. Present name Alyssa Kathleen Anker changed to proposed name Alyssa Kathleen Bobczynski. THE COURT ORDERS that all persons interested in this matter appear before this Court at the hearing indicated below to show cause, if any, why the petition for a change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing. NOTICE OF HEARING: On on July 08, 2016 at 9:30 a.m Dept 46 of the Superior Court of California, 220 W Broadway, San Diego CA 92101. Date: May 16, 2016 Jeffrey B Barton Judge of the Superior Court 05/27, 06/03, 06/10, 06/17/16 CN 18706
Fictitious Business Name Statement #2016-015788 Filed: Jun 08, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Wild Craft Oils Located at: 263 Delphinium St, Encinitas CA San Diego 92024 Mailing Address: Same This business is hereby registered by the following: 1. Piper Lacy, 263 Delphinium St, Encinitas CA 92024; 2. Greg Regan, 263 Delphinium St, Encinitas CA 92024 This business is conducted by: A Married Couple The first day of business was: 04/01/16 S/Piper Lacy, 06/17, 06/24, 07/01, 07/08/16 CN 18813
Fictitious Business Name Statement #2016-015690 Filed: Jun 08, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Sunrise Mortgage and Financial Services Located at: 323 N Coast Hwy #G, Oceanside CA San Diego 92054 Mailing Address: 4413 White Pine Way, Oceanside CA 92057 This business is hereby registered by the following: 1. Teresita A Murphy, 4413 White Pine Way, Oceanside CA 92057 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Teresita A Murphy, 06/17, 06/24, 07/01, 07/08/16 CN 18812
Fictitious Business Name Statement #2016-015687 Filed: Jun 07, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Sunrise Realty and Financial Services Located at: 323 N Coast Hwy #G, Oceanside CA San Diego 92054 Mailing Address: 4413 White Pine Way, Oceanside CA 92057 This business is hereby registered by the following: 1. Teresita A Murphy, 4413 White Pine Way, Oceanside CA 92057 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Teresita A Murphy, 06/17, 06/24, 07/01, 07/08/16 CN 18811
Fictitious Business Name Statement #2016-015480 Filed: Jun 06, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Streamline Pool and Spa Located at: 2934 Preece St, San Diego CA San Diego 92111 Mailing Address: Same This business is hereby registered by the following: 1. Jamison Eichenlaub, 2934 Preece St, San Diego CA 92111 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Jamison Eichenlaub, 06/17, 06/24, 07/01, 07/08/16 CN 18810
Fictitious Business Name Statement #2016-015665 Filed: Jun 07, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Salsify Celebrations; B. Native Plant Celebrations Located at: 20357 Highway 76, Pauma Valley CA San Diego 92061 Mailing Address: 1125 Linda Vista Dr #101, San Marcos CA 92078-3819 This business is hereby registered by the following: 1. Michael W Russ, 2403 Torrejon Pl, Carlsbad CA 92009; 2. Ann Worthington-Russ, 2403 Torrejon Pl, Carlsbad CA 92009 This business is conducted by: A Married Couple The first day of business was: 01/01/15 S/Ann Worthington-Russ, 06/17, 06/24, 07/01, 07/08/16 CN 18809
Fictitious Business Name Statement #2016-014894 Filed: Jun 01, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Regis Consulting Group Located at: 1780 Haydn Dr, Cardiff CA San Diego 92007 Mailing Address: Same This business is hereby registered by the following: 1. Regis Consulting Group LLC, 1780 Haydn Dr, Cardiff CA 92007 This business is conducted by: A Limited Liability Company The first day of business was: 02/14/16 S/Cathy Zaitzow, 06/17, 06/24, 07/01, 07/08/16 CN 18808
Fictitious Business Name Statement #2016-015058 Filed: Jun 02, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Oceanside 420 Alternative Medicine Evaluation Center Located at: 214 N Coast Hwy, Oceanside CA San Diego 92054 Mailing Address: Same This business is hereby registered by the following: 1. Oceanside 420 Alternative Medicine Evaluation Center Inc, 214 N Coast Hwy, Oceanside CA 92054 This business is conducted by: A Corporation The first day of business was: 07/07/11 S/Michelle R Giberti, 06/17, 06/24, 07/01, 07/08/16 CN 18807
Fictitious Business Name Statement #2016-016031 Filed: Jun 10, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. MB Real Estate Group; B. MB Realty Group Located at: 2145 Corte Cidro, Carlsbad CA San Diego 92009 Mailing Address: Same This business is hereby registered by the following: 1. Mehrdad Barhaghi, 2145 Corte Cidro, Carsbad CA 92009 This business is conducted by: An Individual The first day of business was: 06/10/16 S/Medrdad Barhaghi, 06/17, 06/24, 07/01, 07/08/16 CN 18806
Fictitious Business Name Statement #2016-015521 Filed: Jun 06, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Macedo’s Elotes Located at: 1470 Portofino Dr, Vista CA San Diego 92081 Mailing Address: Same This business is hereby registered by the following: 1. Victor Macedo, 1470 Portofino Dr, Vista CA 92081 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Victor Macedo, 06/17, 06/24, 07/01, 07/08/16 CN 18805
Fictitious Business Name Statement #2016-015173 Filed: Jun 03, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Hirecare; B. Hirecare Healthcare Personnel Service Located at: 1340 W Valley Pkwy, Escondido CA San Diego 92029 Mailing Address: Same This business is hereby registered by the following: 1. Hireground Personnel Services Inc, 1340 W Valley Pkwy, Escondido CA 92029 This business is conducted by: A Corporation The first day of business was: 12/13/04 S/David Radel, 06/17, 06/24, 07/01, 07/08/16 CN 18804
Fictitious Business Name Statement #2016-015565 Filed: Jun 07, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Cultivating Peace and Joy Located at: 5205 Avenida Encinas #A, Carlsbad CA San Diego 92008 Mailing Address: Same This business is hereby registered by the following: 1. Kelley L Grimes, 2633 Banbury Ct, Carlsbad CA 92010 This business is conducted by: An Individual The first day of business was: 06/01/16 S/Kelley L Grimes, 06/17, 06/24, 07/01, 07/08/16 CN 18803
Fictitious Business Name Statement #2016-015027 Filed: Jun 02, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. C.A.S.E. Inc Located at: 785 Grand Ave #101, Carlsbad CA San Diego 92008 Mailing Address: Same This business is hereby registered by the following: 1. Comprehensive Autism Services and Education, 785 Grand Ave #101, Carlsbad CA 92008 This business is conducted by: A Corporation The first day of business was: 11/09/99 S/Cynthia LaBrie Norall, 06/17, 06/24, 07/01, 07/08/16 CN 18802
Fictitious Business Name Statement #2016-015812 Filed: Jun 08, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Breeze Hill Located at: 1180 La Tortuga Dr, Vista CA San Diego 92081 Mailing Address: Same This business is hereby registered by the following: 1. Breeze Hill Art LLC, 1180 La Tortuga Dr, Vista CA 92081 This business is conducted by: A Limited Liability Company The first day of business was: Not Yet Started S/Darla Nyren, 06/17, 06/24, 07/01, 07/08/16 CN 18801
Fictitious Business Name Statement #2016-015911 Filed: Jun 09, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Bottom Up Located at: 3425 Filoli Circle, Carlsbad CA San Diego 92009 Mailing Address: Same This business is hereby registered by the following: 1. Fusion Lava Corporation, 3425 Filoli Circle, Carlsbad CA 92009 This business is conducted by: A Corporation The first day of business was: Not Yet Started S/Ellen Pait, 06/17, 06/24, 07/01, 07/08/16 CN 18800
Fictitious Business Name Statement #2016-015738 Filed: Jun 08, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Arnibah Vanst Wholesale Located at: 701 Palomar Airport Rd #300, Carlsbad CA San Diego 92011 Mailing Address: Same This business is hereby registered by the following: 1. Arnibah Vanst, 2625 Pirineos Way #217, Carlsbad CA 92009 This business is conducted by: An Indvidual The first day of business was: Not Yet Started S/Arnibah Vanst, 06/17, 06/24, 07/01, 07/08/16 CN 18799
Fictitious Business Name Statement #2016-015283 Filed: Jun 03, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. The Commonwealth Tattoo Located at: 811 25th St, San Diego CA San Diego 92102 Mailing Address: 1414 Minnesota Ave, Oceanside CA 92054 This business is hereby registered by the following: 1. Jordan Pundik, 1414 Minnesota Ave, Oceanside CA 92054; 2. Mandy Pundik, 1414 Minnesota Ave, Oceanside CA 92054 This business is conducted by: A Married Couple The first day of business was: Not Yet Started S/Jordan Pundik, 06/10, 06/17, 06/24, 07/01/16 CN 18792
Fictitious Business Name Statement #2016-014635 Filed: May 27, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. West Coast Rim Repair Located at: 4043 Linda Dr, Oceanside CA San Diego 92056 Mailing Address: Same This business is hereby registered by the following: 1. Victor Serrano, 4043 Linda Dr, Oceanside CA 92056 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Victor Serrano, 06/10, 06/17, 06/24, 07/01/16 CN 18791
Fictitious Business Name Statement #2016-014526 Filed: May 26, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Trujillo’s Window Cleaning Located at: 2519 Via Naranja, Carlsbad CA San Diego 92010 Mailing Address: Same This business is hereby registered by the following: 1. Ryan Trujillo, 2519 Via Naranja, Carlsbad CA 92010 This business is conducted by: An Individual The first day of business was: 05/24/16 S/Ryan Trujillo, 06/10, 06/17, 06/24, 07/01/16 CN 18790
Fictitious Business Name Statement #2016-014801 Filed: May 31, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Stained Glass Communications Located at: 1425 Corte Bravo, San Marcos CA San Diego 92069 Mailing Address: Same This business is hereby registered by the following: 1. Lynne Rose Marian Abrams, 1425 Corte Bravo, San Marcos CA 92069 This business is conducted by: An Individual The first day of business was: 05/31/16 S/Lynne Rose Marian Abrams, 06/10, 06/17, 06/24, 07/01/16 CN 18789
Fictitious Business Name Statement #2016-015138 Filed: Jun 03, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Scott’s Automotive Located at: 1508 N Coast Hwy 101, Encinitas CA San Diego 92024 Mailing Address: Same This business is hereby registered by the following: 1. Scott R Dailey, 1795 Hygeia, Encinitas CA 92024 This business is conducted by: An Individual The first day of business was: 11/20/96 S/Scott R Dailey, 06/10, 06/17, 06/24, 07/01/16 CN 18788
Fictitious Business Name Statement #2016-014017 Filed: May 20, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Sandgroper Enterprises; B. Coastal Drain Located at: 831 Loring St, San Diego CA San Diego 92109 Mailing Address: Same This business is hereby registered by the following: 1. Hamish Dunkley, 831 Loring St, San Diego CA 92109 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Hamish Dunkley, 06/10, 06/17, 06/24, 07/01/16 CN 18787
Fictitious Business Name Statement #2016-014754 Filed: May 31, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. San Diego Poetry Annual Located at: 1953 Huffstatler St #A, Rainbow CA San Diego 92028 Mailing Address: Same This business is hereby registered by the following: 1. San Diego Entertainment & Arts Guild (SDEAG), 1953 Huffstatler St #A, Rainbow CA 92028 This business is conducted by: A Corporation The first day of business was: 02/09/15 S/William Harry Harding, 06/10, 06/17, 06/24, 07/01/16 CN 18786
Fictitious Business Name Statement #2016-015367 Filed: Jun 06, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Robin Reinke LMFT; B. Robin Reinke & Associates Counseling, Located at: 5650 El Camino Real, #130, Carlsbad CA San Diego 92008 Mailing Address: Same This business is hereby registered by the following: 1. Robin Reinke and Associates Counseling, an Individual, Marriage, Family and Child Therapy Corporation, 5650 El Camino Real #130, Carlsbad CA 92008 This business is conducted by: A Corporation The first day of business was: 06/03/16 S/Robin M Reinke, 06/10, 06/17, 06/24, 07/01/16 CN 18785
Fictitious Business Name Statement #2016-013281 Filed: May 12, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Hyatt House Carlsbad, Located at: 5010 Avenida Encinas, Carlsbad CA San Diego 92008 Mailing Address: 28220 Jefferson Ave, Temecula CA 92590 This business is hereby registered by the following: 1. Carlsbad 10 Hospitality LLC, 28220 Jefferson Ave, Temecula CA 92590 This business is conducted by: A Limited Liability Company The first day of business was: 12/03/14 S/Mayank S Patel, 06/10, 06/17, 06/24, 07/01/16 CN 18784
Fictitious Business Name Statement #2016-014480 Filed: May 25, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Homes by Heidi, Located at: 2033 San Elijo Ave #300, Cardiff CA San Diego 92007 Mailing Address: Same This business is hereby registered by the following: 1. William Hays, 3327 Cabo Way, Carlsbad CA 92009 This business is conducted by: An Individual The first day of business was: Not Yet Started S/William Hays, 06/10, 06/17, 06/24, 07/01/16 CN 18783
Fictitious Business Name Statement #2016-014813 Filed: Jun 01, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. GRP Advisor Alliance, Located at: 5670 El Camino Real #E, Carlsbad CA San Diego 92008 Mailing Address: Same This business is hereby registered by the following: 1. Group 3 Financial, 5670 El Camino Real #E, Carlsbad CA 92008 This business is conducted by: A Limited Liability Company The first day of business was: 02/09/15 S/Christopher Giles, 06/10, 06/17, 06/24, 07/01/16 CN 18782
Fictitious Business Name Statement #2016-015083 Filed: Jun 02, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. GB Creative Enterprises, Located at: 4173 Summerview Way, Oceanside CA San Diego 92056 Mailing Address: Same This business is hereby registered by the following: 1. Gabby Battista, 4173 Summerview Way, Oceanside CA 92056 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Gabby Battista, 06/10, 06/17, 06/24, 07/01/16 CN 18781
Fictitious Business Name Statement #2016-015245 Filed: Jun 03, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Fun Pro Entertainment, Located at: 15954 Avenida Calma, Rancho Santa Fe CA San Diego 92091 Mailing Address: Same This business is hereby registered by the following: 1. Miles Pelky, 15954 Avenida Calma, Rancho Santa Fe CA 92091 This business is conducted by: An Individual The first day of business was: 06/03/16 S/Miles Pelky, 06/10, 06/17, 06/24, 07/01/16 CN 18780
Fictitious Business Name Statement #2016-015270 Filed: Jun 03, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Encinitas Pocket Billiards Club, Located at: 1040 Via Marbrisa, Encinitas CA San Diego 92024 Mailing Address: Same This business is hereby registered by the following: 1. Paul R Corsaro, 1040 Via Marbrisa, Encinitas CA 92024 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Paul R Corsaro, 06/10, 06/17, 06/24, 07/01/16 CN 18779
Fictitious Business Name Statement #2016-014067 Filed: May 23, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. EagleBurgmann EJS, Located at: 10038 Marathon Parkway, Lakeside CA San Diego 92040 Mailing Address: Same This business is hereby registered by the following: 1. EagleBurgmann KE Inc, 10038 Marathon Parkway, Lakeside CA 92040 This business is conducted by: A Corporation The first day of business was: 06/10/09 S/Robert G Evans, 06/10, 06/17, 06/24, 07/01/16 CN 18778
Fictitious Business Name Statement #2016-015412 Filed: Jun 06, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Dusteas, Located at: 1906 S Tremont St #B, Oceanside CA San Diego 92054 Mailing Address: Same This business is hereby registered by the following: 1. Dustin Larson, 1906 S Tremont St #B, Oceanside CA 92054 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Dustin Larson, 06/10, 06/17, 06/24, 07/01/16 CN 18777
Fictitious Business Name Statement #2016-014866 Filed: Jun 01, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Coastal Country Real Estate & Mortgage, Located at: 315 S Coast Hwy 101 #W, Encinitas CA San Diego 92024 Mailing Address: Same This business is hereby registered by the following: 1. Joseph Patrick Moris, 1649 Milan Way, San Marcos CA 92078 This business is conducted by: An Individual The first day of business was: 05/05/10 S/Joseph Patrick Moris, 06/10, 06/17, 06/24, 07/01/16 CN 18776
Fictitious Business Name Statement #2016-014334 Filed: May 24, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Ai Gels LLC, Located at: 2717 Glasgow Dr, Carlsbad CA San Diego 92010 Mailing Address: Same This business is hereby registered by the following: 1. Ai Gels LLC, 2717 Glasgow Dr, Carlsbad CA 92010 This business is conducted by: A Limited Liability Company The first day of business was: Not Yet Started S/Jeffrey D Lueschen, 06/10, 06/17, 06/24, 07/01/16 CN 18775
Fictitious Business Name Statement #2016-014758 Filed: May 31, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Your Home Brokerage; B. Coastal Home Brokers, Located at: 3790 Via de la Valle #110E, Del Mar CA San Diego 92014 Mailing Address: Same This business is hereby registered by the following: 1. Your Home Brokerage Inc, 3790 Via de la Valle #110E, Del Mar CA 92014 This business is conducted by: A Corporation The first day of business was: 04/29/16 S/Dianne Reppucci, 06/03, 06/10, 06/17, 06/24/16 CN 18762
Fictitious Business Name Statement #2016-014042 Filed: May 20, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Sun Flour Bagel, Located at: 6955 El Camino Real #105, Carlsbad CA San Diego 92009 Mailing Address: Same This business is hereby registered by the following: 1. Mitsuhiro Numata, 986 Lupine Hills Dr #88, Vista CA 92081; 2. Atsuko Numata, 986 Lupine Hills Dr #88, Vista CA 92081 This business is conducted by: A Married Couple The first day of business was: 02/01/07 S/Mitsuhiro Numata, 06/03, 06/10, 06/17, 06/24/16 CN 18761
Fictitious Business Name Statement #2016-014521 Filed: May 26, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Redhill Shopping Center, Located at: 2187 Newcastle Ave #100, Cardiff CA San Diego 92007 Mailing Address: Same This business is hereby registered by the following: 1. Michael Pedicini, 2187 Newcastle Ave #100, Cardiff CA 92007 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Michael Pedicini, 06/03, 06/10, 06/17, 06/24/16 CN 18760
Fictitious Business Name Statement #2016-013933 Filed: May 20, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Padi’s Plants and Florals; B. Padi’s Floral and Plants, Located at: 481 Christine Ct, Oceanside CA San Diego 92058 Mailing Address: PO Box 716, San Luis Rey CA 92068-0716 This business is hereby registered by the following: 1. Margarita Arvayo, 481 Christina Ct, Oceanside CA 92058 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Margarita Arvayo, 06/03, 06/10, 06/17, 06/24/16 CN 18759
Fictitious Business Name Statement #2016-014503 Filed: May 26, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Healing in Bloom, Located at: 3519 Four Peaks St, Carlsbad CA San Diego 92010 Mailing Address: Same This business is hereby registered by the following: 1. Karyn Kulenovic, 3519 Four Peaks St, Carlsbad CA 92010 This business is conducted by: An Individual The first day of business was: 05/08/16 S/Karyn Kulenovic, 06/03, 06/10, 06/17, 06/24/16 CN 18758
Fictitious Business Name Statement #2016-014652 Filed: May 27, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Greenspoon Marder; B. Greenspoon Marder LLP, Located at: 402 W Broadway #400, San Diego CA San Diego 92101 Mailing Address: Same This business is hereby registered by the following: 1. Kenneth Lance Rogers, 402 W Broadway #400, San Diego CA 92101; 2. Gerald Greenspoon, 402 W Broadway #400, San Diego CA 92101 This business is conducted by: Limited Liability Partnership The first day of business was: 05/24/16 S/Kenneth Lance Rogers, 06/03, 06/10, 06/17, 06/24/16 CN 18757
Fictitious Business Name Statement #2016-014755 Filed: May 31, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Full on Happiness, Located at: 1480 Moraga Rd #I, Moraga CA Contra Costa 94556 Mailing Address: PO Box 223, Cardiff CA 92007 This business is hereby registered by the following: 1. Gina Martini, 1480 Moraga Rd #I, Moraga CA 94556 This business is conducted by: An Individual The first day of business was: 02/11/16 S/Gina Martini, 06/03, 06/10, 06/17, 06/24/16 CN 18756
Fictitious Business Name Statement #2016-014325 Filed: May 24, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Exhibit Graphic Services, Located at: 599 Chesterfield Circle, San Marcos CA San Diego 92069 Mailing Address: Same This business is hereby registered by the following: 1. Donald Lee Bennett, 599 Chesterfield Circle, San Marcos CA 92069 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Donald Lee Bennett, 06/03, 06/10, 06/17, 06/24/16 CN 18755
Fictitious Business Name Statement #2016-014043 Filed: May 20, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Digimod, Located at: 4711 Amberwood Ct, Carlsbad CA San Diego 92008 Mailing Address: Same This business is hereby registered by the following: 1. Ron Kicinski, 4711 Amberwood Ct, Carlsbad CA 92008 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Ron Kicinski, 06/03, 06/10, 06/17, 06/24/16 CN 18754
Fictitious Business Name Statement #2016-013688 Filed: May 17, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. CreativeNurse, Located at: 750 B St. #2740, San Diego CA San Diego 92101 Mailing Address: 3761 Old Pali Rd, Honolulu HI 96817 This business is hereby registered by the following: 1. CreativeNurse Insurance and Finance LLC, 750 B St. #2740, San Diego CA 92101 This business is conducted by: A Limited Liability Company The first day of business was: Not Yet Started S/Jan Hroch, 06/03, 06/10, 06/17, 06/24/16 CN 18753
Fictitious Business Name Statement #2016-014138 Filed: May 23, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Carlsbad Electrical Services, Located at: 7270 Ponto Dr, Carlsbad CA San Diego 92011 Mailing Address: Same This business is hereby registered by the following: 1. Linden Broccoli, 7270 Ponto Dr, Carlsbad CA 92011 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Linden Broccoli, 06/03, 06/10, 06/17, 06/24/16 CN 18752
Fictitious Business Name Statement #2016-013949 Filed: May 20, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Baja Border Tours LLC, Located at: 5370 Rio Plata Dr, Oceanside CA San Diego 92057 Mailing Address: Same This business is hereby registered by the following: 1. Baja Border Tours LLC, 5370 Rio Plata Dr, Oceanside CA 92057 This business is conducted by: A Limited Liability Company The first day of business was: Not Yet Started S/West J Barba, 06/03, 06/10, 06/17, 06/24/16 CN 18751
Fictitious Business Name Statement #2016-014458 Filed: May 25, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Anchored Health Center, Located at: 6120 Paseo del Norte #L-2, Carlsbad CA San Diego 92011 Mailing Address: Same This business is hereby registered by the following: 1. Juergen G Winkler MD, A Medical Corporation, 6120 Paseo del Norte #L-2, Carlsbad CA 92011 This business is conducted by: A Corporation The first day of business was: Not Yet Started S/Juergen G Winkler, 06/03, 06/10, 06/17, 06/24/16 CN 18750
Fictitious Business Name Statement #2016-014261 Filed: May 24, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Roxy Catering, Located at: 511 S Coast Hwy 101 #216, Encinitas CA San Diego 92024 Mailing Address: Same This business is hereby registered by the following: 1. SHN Inc, 511 S Coast Hwy 101 #216, Encinitas CA 92024 This business is conducted by: A Corporation The first day of business was: Not Yet Started S/Shojaeddin Naimi, 05/27, 06/03, 06/10, 06/17/16 CN 18734
Fictitious Business Name Statement #2016-013057 Filed: May 11, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Ketones Rule, Located at: 604 Saltgrass Ave, Carlsbad CA San Diego 92011 Mailing Address: Same This business is hereby registered by the following: 1. Michael Rutherford, 604 Saltgrass Ave, Carlsbad CA 92011 This business is conducted by: An Individual The first day of business was: 05/21/15 S/Michael Rutherford, 05/27, 06/03, 06/10, 06/17/16 CN 18733
Fictitious Business Name Statement #2016-013609 Filed: May 17, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Johnson Custom Van Solutions, Located at: 846 Cordova St, San Diego CA San Diego 92107 Mailing Address: Same This business is hereby registered by the following: 1. Andrea R Johnson, 846 Cordova St, San Diego CA 92107; 2. Ernest R Johnson, 846 Cordova St, San Diego CA 92107 This business is conducted by: A Married Couple The first day of business was: 05/14/16 S/Andrea R Johnson, 05/27, 06/03, 06/10, 06/17/16 CN 18732
Fictitious Business Name Statement #2016-013955 Filed: May 20, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. The Good Stuff Distribution Company, Located at: 4104 La Portalada Dr, Carlsbad CA San Diego 92010 Mailing Address: Same This business is hereby registered by the following: 1. Michael Staudt, 4104 La Portalada Dr, Carlsbad CA 92010 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Michael Staudt, 05/27, 06/03, 06/10, 06/17/16 CN 18730
Fictitious Business Name Statement #2016-013676 Filed: May 17, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Personal Divorce Coaching, Located at: 1840 Blue Bonnet Pl, Encinitas CA San Diego 92024 Mailing Address: Same This business is hereby registered by the following: 1. Sharon Pearah, 1840 Blue Bonnet Pl, Encinitas CA 92024 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Sharon Pearah, 05/27, 06/03, 06/10, 06/17/16 CN 18729
Fictitious Business Name Statement #2016-013606 Filed: May 17, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Iacobelli Real Estate, Located at: 525 Pina Ln, Vista CA San Diego 92083 Mailing Address: Same This business is hereby registered by the following: 1. Cristina Iacobelli, 525 Pina Ln, Vista CA 92083 This business is conducted by: An Individual The first day of business was: 09/03/15 S/Cristina Iacobelli, 05/27, 06/03, 06/10, 06/17/16 CN 18728
Fictitious Business Name Statement #2016-013610 Filed: May 17, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Alexander Real Estate and Iacobelli Real Estate, Located at: 525 Pina Ln, Vista CA San Diego 92083 Mailing Address: Same This business is hereby registered by the following: 1. Alexander Baur, 525 Pina Ln, Vista CA 92083; 2. Cristina Iacobelli, 525 Pina Ln, Vista CA 92083 This business is conducted by: A General Partnership The first day of business was: 02/01/16 S/Cristina Iacobelli, 05/27, 06/03, 06/10, 06/17/16 CN 18727
Fictitious Business Name Statement #2016-013608 Filed: May 17, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Alexander Real Estate, Located at: 6419 La Paloma St, Carlsbad CA San Diego 92009 Mailing Address: Same This business is hereby registered by the following: 1. Alexander Winfried Baur, 6419 La Paloma St, Carlsbad CA 92009 This business is conducted by: An Individual The first day of business was: 01/01/16 S/Alexander Winfried Baur, 05/27, 06/03, 06/10, 06/17/16 CN 18726
Fictitious Business Name Statement #2016-014001 Filed: May 20, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. 608, Located at: 608 Mission Ave, Oceanside CA San Diego 92054 Mailing Address: 632 S Coast Hwy 101, Encinitas CA 92024 This business is hereby registered by the following: 1. Mazatlan Inc, 632 S Coast Hwy 101, Encinitas CA 92024 This business is conducted by: A Corporation The first day of business was: Not Yet Started S/Jaime Osuna, 05/27, 06/03, 06/10, 06/17/16 CN 18725
Fictitious Business Name Statement #2016-013752 Filed: May 18, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Vital Blends, Located at: 3985 Hibiscus Circle, Carlsbad CA San Diego 92008 Mailing Address: Same This business is hereby registered by the following: 1. Kelly Romanello, 3985 Hibiscus Circle, Carlsbad CA 92008 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Kelly Romanello, 05/27, 06/03, 06/10, 06/17/16 CN 18724
Fictitious Business Name Statement #2016-013522 Filed: May 16, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Torreyana, Located at: 7977 Camino Gato, Carlsbad CA San Diego 92009 Mailing Address: Same This business is hereby registered by the following: 1. Robert Prohaska, 7977 Camino Gato, Carlsbad CA 92009; 2. Mary Lou Prohaska, 7977 Camino Gato, Carlsbad CA 92009 This business is conducted by: A Married Couple The first day of business was: 05/01/16 S/Robert Prohaska, 05/27, 06/03, 06/10, 06/17/16 CN 18723
Fictitious Business Name Statement #2016-013665 Filed: May 17, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. SABIR Therapy Services, Located at: 2714 Loker Ave West #120, Carlsbad CA San Diego 92010 Mailing Address: Same This business is hereby registered by the following: 1. SABIR Physical Therapy Services Inc, 2714 Loker Ave West #120, Carlsbad CA 92078 This business is conducted by: A Corporation The first day of business was: 04/01/16 S/Jon Kern, 05/27, 06/03, 06/10, 06/17/16 CN 18722
Fictitious Business Name Statement #2016-013192 Filed: May 11, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Rising Storm Stables, Located at: 2635 N Twin Oaks Valley Rd, San Marcos CA San Diego 92069 Mailing Address: 4540 Merrill St, Torrance CA 90503 This business is hereby registered by the following: 1. Elizabeth Easton, 2635 N Twin Oaks Valley Rd, San Marcos CA 92069; 2. Roy Easton, 4540 Merrill St, Torrance CA 90503; 3. Myriam Easton, 4540 Merrill St, Torrance CA 90503 This business is conducted by: A General Partnership The first day of business was: 02/04/11 S/Elizabeth Easton, 05/27, 06/03, 06/10, 06/17/16 CN 18721
Fictitious Business Name Statement #2016-013792 Filed: May 18, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Mad Mathematician Tutoring, Located at: 965 Laguna Dr #4, Carlsbad CA San Diego 92008 Mailing Address: Same This business is hereby registered by the following: 1. Matthew Louis Gurdine, 965 Laguna Dr #4, Carlsbad CA 92008 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Matthew Louis Gurdine, 05/27, 06/03, 06/10, 06/17/16 CN 18720
Fictitious Business Name Statement #2016-013121 Filed: May 11, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Maans Mediterranean Grill, Located at: 4259 Oceanside Blvd #107, Oceanside CA San Diego 92056 Mailing Address: Same This business is hereby registered by the following: 1. Sub Centro Inc, 4259 Oceanside Blvd #107, Oceanside CA 92056 This business is conducted by: A Corporation The first day of business was: 05/10/11 S/Maan Charik, 05/27, 06/03, 06/10, 06/17/16 CN 18719
Fictitious Business Name Statement #2016-013260 Filed: May 12, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. LaRue Realty Group; B. Pacific Blue Realty Group, Located at: 2341 Montgomery Ave, Cardiff CA San Diego 92007 Mailing Address: Same This business is hereby registered by the following: 1. Lisa LaRue, 2341 Montgomery Ave, Cardiff CA 92007 This business is conducted by: An Individual The first day of business was: 05/12/16 S/Lisa LaRue, 05/27, 06/03, 06/10, 06/17/16 CN 18718
Fictitious Business Name Statement #2016-013526 Filed: May 16, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Labrum Capital Advisors; B. Vetted Advisor; C. LWM 401(k) & Retirement Plan Services; D. Smart Index Investing; E. Smart Index Advisors; F. Smart Index Portfolios; G. Vetted Advisors, Located at: 6128 Innovation Way, Carlsbad CA San Diego 92009 Mailing Address: Same This business is hereby registered by the following: 1. Labrum Wealth Management LLC, 6128 Innovation Way, Carlsbad CA 92009 This business is conducted by: A Limited Liability Company The first day of business was: 09/11/09 S/Jason R Labrum, 05/27, 06/03, 06/10, 06/17/16 CN 18717
Fictitious Business Name Statement #2016-013633 Filed: May 17, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Fairchild Marketing; B. Fairchild Marketing Group, Located at: 3288 5th Ave #516, San Diego CA San Diego 92103 Mailing Address: Same This business is hereby registered by the following: 1. Amy Fairchild, 3288 5th Ave #516, San Diego CA 92103 This business is conducted by: An Individual The first day of business was: 03/01/15 S/Amy Fairchild, 05/27, 06/03, 06/10, 06/17/16 CN 18716
Fictitious Business Name Statement #2016-014126 Filed: May 23, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Enlight Flame, Located at: 6361 Yarrow Dr #B, Carlsbad CA San Diego 92011 Mailing Address: Same This business is hereby registered by the following: 1. Randi Ranae, 14315 Calle de Vista Rd, Valley Center CA 92082; 2. Chad Soren, 14315 Calle de Vista Rd, Valley Center CA 92082 This business is conducted by: A General Partnership The first day of business was: Not Yet Started S/Chad Soren, 05/27, 06/03, 06/10, 06/17/16 CN 18715
Fictitious Business Name Statement #2016-013653 Filed: May 17, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Encinitas Surfboards Inc; B. Encinitas Surf & Sport; C. Encinitas Surf Shop; D. Surfboards Encinitas; E. Encinitas Surf Shoppe, Located at: 107 N Coast Hwy 101, Encinitas CA San Diego 92024 Mailing Address: Same This business is hereby registered by the following: 1. Encinitas Surfboards Inc, 107 N Coast Hwy 101, Encinitas CA 92024 This business is conducted by: A Corporation The first day of business was: 12/05/75 S/Marc Adam, 05/27, 06/03, 06/10, 06/17/16 CN 18714
Fictitious Business Name Statement #2016-013529 Filed: May 16, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Celebration Boutique, Located at: 8898 Gowdy Ave, San Diego CA San Diego 92123 Mailing Address: Same This business is hereby registered by the following: 1. Van Trinh, 8898 Gowdy Ave, San Diego CA 92123 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Van Trinh, 05/27, 06/03, 06/10, 06/17/16 CN 18713
Fictitious Business Name Statement #2016-013891 Filed: May 19, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Blue Stone Properties LLC, Located at: 1023 Neptune Ave, Encinitas CA San Diego 92024 Mailing Address: PO Box 231325, Encinitas CA 92023 This business is hereby registered by the following: 1. Blue Stone Properties LLC, 1023 Neptune Ave, Encinitas CA 92024 This business is conducted by: A Limited Liability Company The first day of business was: Not Yet Started S/Thomas Hewitt, 05/27, 06/03, 06/10, 06/17/16 CN 18712
Fictitious Business Name Statement #2016-013374 Filed: May 13, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. BeeMan Removal & Relocation, Located at: 1104 Highland Dr, Del Mar CA San Diego 92014 Mailing Address: Same This business is hereby registered by the following: 1. Mark Gadbois, 1104 Highland Dr, Del Mar CA 92014 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Mark Gadbois, 05/27, 06/03, 06/10, 06/17/16 CN 18711
Fictitious Business Name Statement #2016-013545 Filed: May 16, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Art of Living Medicine, Located at: 906 21st St #10, San Diego CA San Diego 92102 Mailing Address: Same This business is hereby registered by the following: 1. Rachel Couch, 906 21st St #10, San Diego CA 92102 This business is conducted by: An Individual The first day of business was: 04/16/16 S/Rachel Lorainne Couch, 05/27, 06/03, 06/10, 06/17/16 CN 18710
Fictitious Business Name Statement #2016-013471 Filed: May 16, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. All Phone Company, Located at: 1355 Rocky Point Dr, Oceanside CA San Diego 92056 Mailing Address: Same This business is hereby registered by the following: 1. E Recycler Inc, 1355 Rocky Point Dr, Oceanside CA 92056 This business is conducted by: A Corporation The first day of business was: Not Yet Started S/Jeffrey Dougherty, 05/27, 06/03, 06/10, 06/17/16 CN 18709
Fictitious Business Name Statement #2016-012007 Filed: Apr 28, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. 1st Street Bar, Located at: 656 S Coast Hwy 101, Encinitas CA San Diego 92024 Mailing Address: Same This business is hereby registered by the following: 1. 1st Things LLC, 656 S Coast Hwy 101, Encinitas CA 92024 This business is conducted by: A Limited Liability Company The first day of business was: 07/02/15 S/David Shapiro, 05/27, 06/03, 06/10, 06/17/16 CN 18708
